Seattle Washington Construction Expert Witness Directory

No Damages for Delay May Not Be Enforceable in Virginia

January 08, 2024 — Christopher G. Hill - Construction Law Musings
Anyone who reads Construction Law Musings with any regularity (thank you by the way) knows that the contract is king in most instances here in Virginia. Any commercial construction subcontractor in Virginia is likely also very familiar with so-called “no damages for delay” clauses in construction contracts. These clauses essentially state that a subcontractor’s only remedy for a delay caused by any factor beyond its control (including the fault of the general contractor), after proper notice to the general contractor, is an extension of time to complete the work. However, in 2015 the Virginia General Assembly passed a change in the law that precluded the diminishment of any right to claims for demonstrated additional costs prior to payment. This left open the question as to which types of “diminishment” would be barred by the statute. The recent case out of the Eastern District of Virginia federal court, Strata Solar LLC v. Fall Line Construction LLC, added a bit of clarity. Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Drawing the Line: In Tennessee, the Economic Loss Doctrine Does Not Apply to Contracts for Services

December 11, 2023 — Gus Sara - The Subrogation Strategist
In Commercial Painting Co. v. Weitz Co. LLC, No. W2019-02089-SC-R11-CV, 2023 Tenn. LEXIS 39 (Weitz), the Supreme Court of Tennessee (Supreme Court) considered whether the economic loss doctrine barred the plaintiff’s claims for fraud, negligent misrepresentation and punitive damages arising out of a contract with the defendant for construction services. The court held that the economic loss doctrine only applies to product liability cases and does not apply to claims arising from contracts for services. This case establishes that, in Tennessee, the economic loss doctrine does not bar tort claims in disputes arising from service contracts. In Weitz, defendant, Weitz Co. LLC (Weitz), was the general contractor for a construction project and hired plaintiff Commercial Painting Co. (Commercial) as a drywall subcontractor. Weitz refused to pay Commercial for several of its payment applications, claiming that the applications were submitted untimely and contained improper change order requests. Commercial filed a lawsuit against Weitz seeking over $1.9 million in damages, alleging breach of contract, unjust enrichment, enforcement of a mechanic’s lien, and interest and attorney’s fees under the Prompt Pay Act of 1991. Weitz filed a counterclaim for $500,000 for costs allegedly incurred due to Commercial’s delay and defective workmanship. In response, Commercial amended its complaint to add claims for fraud, intentional and negligent misrepresentation, rescission of the contract and $10 million in punitive damages. Commercial alleged that Weitz received an extension of the construction schedule but fraudulently withheld this information from Commercial and continued to impose unrealistic deadlines. Read the full story...
Reprinted courtesy of Gus Sara, White and Williams
Mr. Sara may be contacted at sarag@whiteandwilliams.com

NYC Hires Engineer LERA for Parking Garage Collapse Probe

January 29, 2024 — James Leggate - Engineering News-Record
The investigation into the collapse of a Lower Manhattan parking garage last April is still underway. A Jan. 2 notice published in The City Record identified LERA Consulting Structural Engineers RLLP as the engineering firm assisting with the probe. Reprinted courtesy of James Leggate, Engineering News-Record Mr. Leggate may be contacted at leggatej@enr.com Read the full story...

CGL Policy May Not Cover Cybersecurity and Data-Related Losses

March 25, 2024 — Susana Arce - Saxe Doernberger & Vita, P.C.
The construction industry, like many other industries, has experienced an increased reliance on, and implementation of, technology in the past few years. Smart phones and tablets are used on most project sites, computers are an integral part of the planning process, and various software programs are used throughout the construction process. Likewise, much of the machinery and equipment used during construction (e.g., total stations, trucks, tower cranes) is interconnected, and in some cases, operated or monitored remotely.1 With an increase in technology comes a risk of cybersecurity and data-related losses. Many large businesses purchase Commercial General Liability (“CGL”) insurance and assume cybersecurity and data-related losses are covered. Unfortunately, this is generally not the case. CGL policies typically cover three general types of damage: bodily injury, property damage, and advertising injury. Read the full story...
Reprinted courtesy of Susana Arce, Saxe Doernberger & Vita, P.C.
Ms. Arce may be contacted at SArce@sdvlaw.com

Gaps in Insurance Created by Complex Risks

January 22, 2024 — The Hartford Staff - The Hartford Insights
From slips, trips and falls to extreme weather and cyberattacks, businesses are regularly confronted with risks to operations and profitability. In 2023, elevated building costs, increased flooding, and growing ransomware attacks made it compelling for business owners to make sure they had adequate insurance to stay ahead of property and liability exposures. However, if left unchecked, these trends can lead to gaps in coverage. As 2024 approaches, now is the time to assess your risk and collaborate with the right resources to fill any potential voids in insurance. Economic inflation for example has changed property valuations, which can result in coverage gaps if policyholders have not examined their replacement costs recently. Read the full story...
Reprinted courtesy of The Hartford Staff, The Hartford Insights

Meet the Forum's ADR Neutrals: TOM NOCAR

March 25, 2024 — Marissa L. Downs - The Dispute Resolver
Company: Hahn Loeser & Parks, LLP Office Location: Columbus, Ohio Email: tnocar@hahnlaw.com Website: https://www.hahnlaw.com/professionals/j-thomas-nocar/ Law School: The Ohio State University Moritz College of Law Types of ADR services offered: Arbitration and Mediation Affiliated ADR organizations: AAA Construction Panel Geographic area served: Nationwide Q: Describe the path you took to becoming an ADR neutral. A: I am a former builder turned construction attorney. I spent 26 years building before going to law school. I’ve worn every hat in the industry—D/B business owner, owner’s rep, CM at risk, GC, design/builder, subcontractor, and vendor at some point in my prior career. I chose to adapt these experiences to a law career in 2009 with the focus of practicing construction law. Now I commonly represent commercial builders and developers. AAA added me to the Construction Roster in 2022. Read the full story...
Reprinted courtesy of Marissa L. Downs, Laurie & Brennan, LLP
Ms. Downs may be contacted at mdowns@lauriebrennan.com

When OSHA Cites You

April 22, 2024 — Michael Metz-Topodas - Construction Executive
With the strong bonds that form among construction project teams, workers looking out for each other helps keep safety foremost in everyone’s mind. But sometimes, even the very best intentions alone can’t prevent an occasional misstep—a forgotten hard hat, a sagging rope line—which can and often does result in an OSHA citation. These regulatory reminders can bring unfortunate consequences: penalties, higher insurance premiums, potential worker injury claims, loss of bidding eligibility, loss of reputation and even public embarrassment, because citations are published on OSHA’s website. Due to citations’ adverse effects, contractors have incentives to minimize them. They can do this by asserting available defenses, because a citation is only an alleged violation, not a confirmed one. But making defenses available begins well before a citation is issued, well before OSHA arrives to a construction site and well before a violation even occurs. Instead, contractors’ ongoing safety programs should incorporate the necessary measures to preserve OSHA citation defenses in three key areas: lack of employee exposure, lack of employer knowledge and impossibility. EMPLOYEE EXPOSURE To sustain a citation against an employer, OSHA must not only identify an applicable standard that the company violated but also show that the violation exposed employees to hazards and risk of injury. Absent evidence of actual exposure, OSHA often makes this showing by asserting that performing job functions necessarily exposes employees to the cited hazard. Reprinted courtesy of Michael Metz-Topodas, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...
Mr. Metz-Topodas may be contacted at michael.metz-topodas@saul.com

Kahana Feld Welcomes Six Attorneys to the Firm in Q4 of 2023

January 16, 2024 — Linda Carter - Kahana Feld
Kahana Feld is pleased to announce the addition of six attorneys to the team in the fourth quarter of 2023. We are excited to have each of these individuals on the team. In our Houston office, Kahana Feld welcomes Partner Donald Loving II and Attorney Elliott Wright. Mr. Loving is a member of the General Liability and Trucking & Transportation practice groups. He earned his Juris Doctor from the University of Houston and has over 30 years of litigation and trial experience, including working as staff & corporate counsel for several prominent insurance carriers including GEICO, Progressive, USAA and Travelers. Mr. Wright is a member of the Construction Defect, General Liability, and Trucking & Transportation practice groups. He earned his Juris Doctor from SMU Dedman School of Law, and has extensive litigation and insurance defense experience. Read the full story...
Reprinted courtesy of Linda Carter, Kahana Feld
Ms. Carter may be contacted at lcarter@kahanafeld.com

SEATTLE WASHINGTON CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES