SEATTLE WASHINGTON CONSTRUCTION EXPERT WITNESS
DIRECTORY AND CAPABILITIES

Washington Court Denies Subcontractor’s Claim Based on Contractual Change and Notice Provisions

January 29, 2024 — Wendy Rosenstein - Ahlers Cressman & Sleight PLLC
The recent unpublished case, Cascade Civil Construction, LLC v. Jackson Dean Construction, Inc., et al.,[1] provides a legal justification for contractors to require a directive or change order in advance of performing changed work—thereby preventing the party who requested the changed work from later arguing that notice provisions were not complied with. In the case, Jackson Dean, the prime contractor, hired Cascade to perform excavation work on a project to build a new Costco Corporate headquarters. Due to the Covid-19 pandemic and other issues, Jackson Dean directed resequencing, which required Cascade to perform excavation concurrent to dewatering. Jackson Dean also required deeper-than-planned excavation under one of the buildings. Read the full story...
Reprinted courtesy of Wendy Rosenstein, Ahlers Cressman & Sleight PLLC
Ms. Rosenstein may be contacted at wendy.rosenstein@acslawyers.com

---

The Word “Estimate” in a Contract Matters as to a Completion Date

February 12, 2024 — David Adelstein - Florida Construction Legal Updates
Language in a contract matters. The word “estimates” or “estimated” matters particularly when it comes to a date certain such as a substantial completion or completion date. Remember this. Here is an example. In Parque Towers Developers, LLC v. Pilac Management, Ltd., 49 Fla.L.Weekly D190a (Fla. 3d DCA 2024), a trial court held that the developer did not complete the construction of five condominium units by the date in the purchase agreements. The developer appealed because “[t]he agreements contain no date certain for the completion of the units, but rather include a clause that ‘Seller estimates it will substantially complete construction of the Unit, in the manner specified in this Agreement, by December 31, 2017, subject to extensions resulting from ‘Force Majeure (the ‘Outside Date’).’” Parque Towers, supra. Another provision in the purchase agreements stated, “[w]henver this Agreement requires Seller to complete or substantially complete any item of construction, that item will be understood to be complete or substantially complete when so completed or substantially completed in Seller’s opinion. Id. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Certificates of Merit: Is Your Texas Certificate Sufficient?

January 22, 2024 — Gus Sara - The Subrogation Strategist
In Eric L. Davis Eng’g, Inc. v. Hegemeyer, No. 14-22-00657-CV, 2023 Tex. App. LEXIS 8899, the Court of Appeals of Texas (Court of Appeals) considered whether the plaintiffs’ certificate of merit, in support of their professional malpractice claim against the defendant engineers, adequately set forth the experience and qualifications of the expert who submitted the certificate. The defendants filed a motion to dismiss, alleging that the certificate of merit was inadequate because it failed to establish that the expert practiced in the same specific areas as the defendants in relation to the work at issue. The lower court denied the defendants’ motion. The Court of Appeals affirmed the lower court’s decision, finding that there was sufficient information for the lower court to have reasonably found that the plaintiffs’ expert practiced in the same area as the defendants. In Hegemeyer, the plaintiffs sued Eric L. Davis Engineering, Inc. (Davis) and Kenneth L. Douglass (Douglass), alleging improper design of their home’s foundation. The plaintiffs retained Davis to design and engineer the home and Douglass prepared the plans for the home. The plans called for the installation of post-tension cables in the home’s foundation. The plaintiffs alleged that the foundation design was improper and brought professional malpractice claims against Davis and Douglass. Read the full story...
Reprinted courtesy of Gus Sara, White and Williams
Mr. Sara may be contacted at sarag@whiteandwilliams.com

---

Allegations Versus “True Facts”: Which Govern the Duty to Defend? Bonus! A Georgia Court Clears Up What the Meaning of “Is” Is

December 11, 2023 — Rachel E. Hudgins & Syed S. Ahmad - Hunton Insurance Recovery Blog
Courts scrutinize a complaint’s factual allegations to decide whether the allegations trigger a duty to defend. [1] If the facts unambiguously exclude coverage, there is no duty to defend. [2] But what if the factual allegations fall within a policy exclusion, but the allegations are untrue or questionable? What if the true facts would mean the exclusion doesn’t apply? In that case, many courts have found that the insurer should base its decision on the policyholder’s version of the “true facts.” [3] An insurer can’t rely on the complaint’s allegations to deny coverage when the facts that the insurer knows or can ascertain show that the claim is covered. [4] A recent case, United Minerals & Properties Inc. v. Phoenix Insurance Co., No. 4:23-cv-00050 (N.D. Ga.), illustrates these policy interpretation principles. Reprinted courtesy of Rachel E. Hudgins, Hunton Andrews Kurth and Syed S. Ahmad, Hunton Andrews Kurth Ms. Hudgins may be contacted at rhudgins@HuntonAK.com Mr. Ahmad may be contacted at sahmad@HuntonAK.com Read the full story...

---

Real Estate & Construction News Roundup (3/6/24) – Steep Drop in Commercial Real Estate Investment, Autonomous Robots Being Developed for Construction Projects, and Treasury Department Proposes Regulation for Real Estate Professionals

April 08, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, major league sports franchises turn to real estate to increase their value, the Associated Builders and Contractors releases a guide on artificial intelligence, New York City helps landlords convert empty office space into housing, and more!

• The Treasury Department proposed a regulation that would require real estate professionals to report information to the agency about all-cash sales of residential real estate to legal entities, trusts and shell companies. (Fatima Hussein, AP)
• For decades, major league teams depended on ticket sales, concessions and TV deals to generate revenue, but team owners in recent years have turned to real estate development to bring in extra cash and drive up the values of their franchises. (Nathaniel Meyersohn, CNN)
• The U.S. commercial real estate market saw a steep drop in investment last year, with the market plummeting by more than 50% to the lowest level since 2012 and CBRE noting a 91% year-over-year drop in direct real estate company investments. (Yuheng Zhan, Business Insider)

Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

---

Finding an "Occurrence," Appellate Court Rules Insurer Must Defend

March 11, 2024 — Tred R. Eyerly - Insurance Law Hawaii
Reversing the trial court, the Wisconsin Court of Appeals found the insurer must defend a cross-claim against the insured owner of a building after an explosion occurred. LBC, LLC v Spectrum Brands, Inc., 2023 Wis. App. LEXIS 1251 (Wis. Ct. App, Nov. 30, 2023). LBC leased commercial property to Spectrum. Spectrum stored lithium on the property. The lithium exploded when it came into contact with water that entered the premises during historic flooding in August 2018. Spectrum remediated the premises, vacated the premises prior to the lease's termination date, and stopped paying rent. LBC sued Spectrum, alleging that Spectrum negligently stored the lithium and that Spectrum breached the lease. Spectrum counterclaimed, alleging that LCB breached the lease in various respects, that LCB negligent allowed water to infiltrate the premises, and that Spectrum was constructively evicted. LCB tendered the counterclaim to its insurer, General Casualty. The tender was denied and LCB sued. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

The Increasing Trend of Caps in Construction Contracts and Negotiating Them

November 27, 2023 — Jarred Trauth - ConsensusDocs
Risks are inherent in every construction project and all parties involved face them: owners, designers, general contractors/builders, subcontractors, suppliers…. Equitably allocating such risks is one of the most important and most negotiated areas of any construction related contract. Limitations of liability provisions are key to risk allocation. These provisions include no damage for delay provisions and caps on delay damages, warranty limitations and exclusions, indemnity limitations, and consequential damage waivers. Another, and the focus of this article, is a liability cap fixing the total amount of damages for which a party may be liable under the contract (the “Liability Cap”). Liability Caps have become more and more common in construction and construction related contracts, including major component supply agreements and design agreements. This article will discuss Liability Caps generally and considerations of an owner or contractor negotiating them, including carve-outs (i.e. exceptions) to them. Read the full story...
Reprinted courtesy of Jarred Trauth, Jones Walker LLP
Mr. Trauth may be contacted at jtrauth@joneswalker.com

---

The Contractor’s Contingency: What Contractors and Construction Managers Need to Know and Be Wary Of

December 04, 2023 — Skyler L. Santomartino - Peckar & Abramson, P.C.
Contractors and construction managers who enter into cost reimbursable contracts subject to a guaranteed maximum price (GMP) are responsible for all project costs exceeding the GMP. For this reason, it is imperative that contractors negotiate and incorporate into the GMP a financial buffer that accounts for the unanticipated project costs that are not reimbursable as change orders or costs of the work. This is where the contractor’s contingency comes into play.[1] The contractor’s contingency is a vehicle that allows contractors to mitigate some of the risks inherent in GMP contracts. When drafted properly, a contingency clause allows the contractor and only the contractor to access funds set aside by the owner to address unpredictable or unknown project costs. Read the full story...
Reprinted courtesy of Skyler L. Santomartino, Peckar & Abramson, P.C.
Mr. Santomartino may be contacted at ssantomartino@pecklaw.com

---