Illinois Supreme Court Finds Construction Defect Claim Triggers Initial Grant of Coverage
February 26, 2024 —
Tred R. Eyerly - Insurance Law HawaiiThe Illinois Supreme Court found that the underlying allegations addressing construction defects were sufficient to establish "property damage" caused by an "occurrence."Acuity v. M/I Homes of Chicago, LLC, 2023 Ill. LEXIS 1019 (Ill. Nov. 30, 2023).
M/I Homes was the general contractor for a residential townhome development. The Owners' Association sued for breach of conract and breach of the implied warranty of habitability against M/I Homes. The complaint alleged that M/I Homes' subcontractors caused construction defects by using defective materials, conducting faulty workmanship and failing to comply with applicable building codes. The defects included leakage and uncontrolled water with moisture in locations in the buildings where it was not intended or expected. The Association further alleged that M/I Homes did not intend to cause the construction defects nor did it expect or intend the resulting property damage, such as damage to other building materials. The complaint further alleged that M/I Homes did not perform any of the construction work and that the subconractors performed all the work on its behalf.
Read the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Meet BWBO’s 2024 San Diego Super Lawyers Rising Stars!
April 29, 2024 —
Bremer Whyte Brown & O'Meara LLPBWB&O is proud to announce San Diego Partner
Johnpaul Salem, and Associates
Christina Matian and
Angelo Perillo have been selected in the 2024 San Diego Super Lawyers list as Rising Stars for their work in Civil and Personal Injury Litigation. To read Super Lawyers’ digital publication, please click
here.
SELECTED AS RISING STARS
Johnpaul Salem: 2023-2024
Christina Matian: 2024
Angelo Perillo: 2024
Super Lawyers is a rating service of outstanding lawyers from more than 70 practice areas who have attained a high degree of peer recognition and professional achievement. The objective of Super Lawyers’ patented multiphase selection process is to create a credible, comprehensive, and diverse listing of outstanding attorneys that can be used as a resource for attorneys and consumers searching for legal counsel.
Read the full story...Reprinted courtesy of
Bremer Whyte Brown & O'Meara LLP
No Damages for Delay May Not Be Enforceable in Virginia
January 08, 2024 —
Christopher G. Hill - Construction Law MusingsAnyone who reads Construction Law Musings with any regularity (thank you by the way) knows that the contract is king in most instances here in Virginia. Any commercial construction subcontractor in Virginia is likely also very familiar with so-called “no damages for delay” clauses in construction contracts. These clauses essentially state that a subcontractor’s only remedy for a delay caused by any factor beyond its control (including the fault of the general contractor), after proper notice to the general contractor, is an extension of time to complete the work. However, in 2015 the Virginia General Assembly passed a change in the law that precluded the diminishment of any right to claims for demonstrated additional costs prior to payment. This left open the question as to which types of “diminishment” would be barred by the statute.
The recent case out of the Eastern District of Virginia federal court, Strata Solar LLC v. Fall Line Construction LLC, added a bit of clarity.
Read the full story...Reprinted courtesy of
The Law Office of Christopher G. HillMr. Hill may be contacted at
chrisghill@constructionlawva.com
Eleventh Circuit Set to Hear Challenge to Florida Law Barring Foreign Citizens From Buying Real Property
April 22, 2024 —
Michael Gnesin - Lewis BrisboisFort Lauderdale, Fla. (April 2, 2024) - This month, the U.S. Court of Appeals for the Eleventh Circuit will hear a challenge to a recently-enacted Florida law, Senate Bill 264, which restricts foreign ownership or investment in Florida real property from specific countries and imposes a near ban on property purchases by Chinese, Russian and other foreign nationals.
On July 1, 2023,
Senate Bill 264 [codified under Fla. Stat. Ann. §§ 692.201 to 692.205] took effect. The bill, titled “Interests of Foreign Countries,” prohibits Chinese nationals and nationals from other countries, including Russia, from buying real property unless they are American citizens or permanent residents.
Prior to the new law's effective date, on May 22, 2023, four Chinese citizens who hold nonimmigrant visas and reside in Florida, along with a Florida-based real estate firm,
sued the state of Florida in federal district court, alleging that the new law is unconstitutional and discriminatory, and that it violates the Fair Housing Act [Shen v. Simpson, Case No. 4:23-cv-208].
Read the full story...Reprinted courtesy of
Michael Gnesin, Lewis BrisboisMr. Gnesin may be contacted at
Michael.Gnesin@lewisbrisbois.com
Graham & Who May Trigger The Need To Protest
December 23, 2023 —
Hugo Fraga - Ahlers Cressman & Sleight PLLCOn May 30, 2023, the Washington Court of Appeals, Division I, issued a decision that appears to expand a contractor’s obligation with respect to WSDOT notice and claim procedures. In
Graham Contracting, Ltd. v. City of Federal Way, No. 83494-1-I, 2023 WL 3721171 (Wash. Ct. App. May 30, 2023) (Unpublished), the Court held that under the 2016 WSDOT Standard Specifications for Road, Bridge, and Municipal Construction (“Standard Specifications”), a Contractor must protest the actions of not only the “Engineer” but also the actions of any person or organization acting on behalf of the Owner.
This case arises out of a public construction contract in which Graham Contracting Ltd (“Graham”) built a multi-million dollar roadway improvement for the City of Federal Way along a stretch of Pacific Highway. The appeal was from the trial court’s granting of the City’s motion for summary judgment to dismiss claims by Graham for extra time and money due to delays and impacts to Graham’s construction of the Project.
Read the full story...Reprinted courtesy of
Hugo Fraga, Ahlers Cressman & Sleight PLLCMr. Fraga may be contacted at
hugo.fraga@acslawyers.com
The National Labor Relations Board Joint Employer Standard is Vacated by the Eastern District of Texas
April 22, 2024 —
Andrew G. Vicknair - The Dispute ResolverMany employment laws use the concept of joint employer to make more than one business entity responsible for complying with employment law obligations towards employees who to varying degrees work for, or under the direction of entities who are not technically the employees primary employer. Nowhere is that issue more prevalent than in contractor subcontractor relationships. Over the years the National Labor Relations Board (NLRB) has developed various tests for determining joint employer status. Unless a business entity is an employer of individuals, the NLRB has no jurisdiction over a dispute between the workers and a business entity for whom they work.
It is important for contractors to understand the importance of being an employer and the obligations that flow from such status. Likewise, it is also important to understand when a contractor may be classified as a “joint employer” over certain individuals. Depending on the specific laws involved, such a finding of joint-employer status can happen under the “joint employer doctrine” which often exists in subcontractor and temporary employment arrangements. The “joint-employer doctrine” may render a contractor responsible for another company’s employment liabilities.
Read the full story...Reprinted courtesy of
Andrew G. Vicknair, D'Arcy Vicknair, LLCMr. Vicknair may be contacted at
agv@darcyvicknair.com
9th Circuit Plumbs Through the Federal and State False Claims Acts
January 16, 2024 —
Garret Murai - California Construction Law BlogYou may have heard of the False Claims Act and know that it penalizes companies and individuals in contract with the government who present false claims. The federal False Claims Act was signed into law by President Abraham Lincoln in 1863 to penalize profiteers during the Civil War who were selling the Union Army moth eaten blankets, boxes of sawdust instead of guns, and sometimes re-selling the Army calvary horses several times over. Since then, many states, including California, as well as municipalities, have enacted their own false claim statutes.
As currently written, the federal False Claims Act provides for statutory penalties against any person who:
- “[K]nowingly presents, or causes to be presented, a false or fraudulent claim for payment or approval”;
- “[K]nowingly makes, uses or causes to be made or used, a false record or statement material to a false or fraudulent claim”;
- “[H]as possession, custody, or control of property or money used, or to be used, by the Government an knowingly delivers, or causes to be delivered, less than all of that money or property”;
Read the full story...Reprinted courtesy of
Garret Murai, Nomos LLPMr. Murai may be contacted at
gmurai@nomosllp.com
Ohio Supreme Court Rules That Wrongful Death Claims Are Subject to the Four-Year Statute of Repose for Medical Claims
January 16, 2024 —
Lewis Brisbois NewsroomCleveland, Ohio (January 2, 2024) - In a landmark 4-3 ruling, the Supreme Court of Ohio ruled on December 28 that wrongful death claims are subject to the four-year statute of repose contained in O.R.C. 2305.113(C) (“Medical Claim Statute of Repose”). Everhart v. Coshocton County Memorial Hospital, Slip No. 2023-Ohio-4670. Statutes of repose create an absolute bar to filing a lawsuit. When applicable, they bar plaintiffs from filing claims outside a specified time frame. The Medical Claim Statute of Repose creates a four-year window for commencing medical claims, which begins to run from “the occurrence of the act or omission constituting the alleged basis of the medical…claim.” O.R.C. 2305.113(C)(1). Medical claims commenced after the four-year period are barred.
The primary question before the Court was whether a wrongful death claim, which is separate and distinct from a medical negligence claim, can qualify as a “medical claim” within the context of the Medical Claim Statute of Repose. The Court answered in the affirmative. A wrongful death claim can qualify as a medical claim if the wrongful death claim “…arises out the medical diagnosis, care, or treatment, of any person.” O.R.C. 2305.113(E)(3). According to the majority, a wrongful death claim can fall within the broad definition of “medical claim” and, if it does, is subject to the Medical Claim Statute of Repose.
Read the full story...Reprinted courtesy of
Lewis Brisbois