Challenging Enforceability of Liquidated Damages (In Federal Construction Context)
March 11, 2024 —
David Adelstein - Florida Construction Legal UpdatesA recent summary judgment opinion from the Armed Services Board of Contract Appeals (ASBCA), Appeals Of – BCI Construction USA, Inc.,ASBCA No. 6257, 2024 WL 773324 (2024), contains a worthy discussion regarding a contractor’s challenge to the government’s assessment of liquidated damages, specifically the enforceability of the liquidated damages rate. Although this challenge is in the federal context, this discussion would be more expansive and apply outside of the federal context.
When dealing with the enforceability of a liquidated damages, the ASBCA “examines whether the liquidated damages amount ‘is extravagant, or disproportionate to the amount of property loss, as to show that compensation was not the object aimed at or as to imply fraud, mistake, circumvention or oppression.” Appeals of – BCI Construction USA, Inc. (citation omitted).
Read the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
American Arbitration Association Revises Construction Industry Rules and Mediation Procedures
April 08, 2024 —
Dennis Cavanaugh & Larry Grijalva - Construction Law ZoneThe American Arbitration Association (AAA), one of the longest-standing and experienced alternative dispute resolution (ADR) administrators, has unveiled a significant update to its Construction Industry Rules and Mediation procedures. This update, last revised in 2015, became effective March 1, 2024. Changes to the AAA Construction Industry Rules are significant as these rules are incorporated by default in American Institute of Architects standard construction forms, which are widely used in the industry.
Advancements in remote access technology drive a substantial number of new changes. Others are designed to streamline the arbitrator appointment process and certain prehearing procedures and to make arbitration more cost-efficient by enhancing the arbitrator’s case management authority. Some of the more notable changes are:
Fast Track
F-1: The limit for cases eligible for AAA’s Fast Track Procedures has been increased from $100,000 to $150,000 so long as no claim or counterclaim exceeds that amount.
Reprinted courtesy of
Dennis Cavanaugh, Robinson & Cole and
Larry Grijalva, Robinson & Cole
Mr. Cavanaugh may be contacted at dcavanaugh@rc.com
Mr. Grijalva may be contacted at lgrijalva@rc.com
Read the full story...
The Contractor’s Contingency: What Contractors and Construction Managers Need to Know and Be Wary Of
December 04, 2023 —
Skyler L. Santomartino - Peckar & Abramson, P.C.Contractors and construction managers who enter into cost reimbursable contracts subject to a guaranteed maximum price (GMP) are responsible for all project costs exceeding the GMP. For this reason, it is imperative that contractors negotiate and incorporate into the GMP a financial buffer that accounts for the unanticipated project costs that are not reimbursable as change orders or costs of the work. This is where the contractor’s contingency comes into play.[
1]
The contractor’s contingency is a vehicle that allows contractors to mitigate some of the risks inherent in GMP contracts. When drafted properly, a contingency clause allows the contractor and only the contractor to access funds set aside by the owner to address unpredictable or unknown project costs.
Read the full story...Reprinted courtesy of
Skyler L. Santomartino, Peckar & Abramson, P.C.Mr. Santomartino may be contacted at
ssantomartino@pecklaw.com
Construction Contract Basics: Attorney Fee Provisions
November 13, 2023 —
Christopher G. Hill - Construction Law MusingsI have discussed the need for
attorney fee provisions in your construction contracts in prior posts here at Construction Law Musings, but thought it merited a restatement of the reasons for the inclusion of such fee provisions (and changing of such provisions when presented) here with the second of my
construction contract basics posts.
Why would you want such a provision? The answer is that without it, or a statute specifically allowing for such fees, a Virginia court will not award your attorney fees without such a provision. Virginia, and a lot of other states, follow the so-called “American Rule” when it comes to attorney fees and costs. In short, that rule states that the parties to litigation pay their own way unless they agree otherwise. While it may seem unfair to make a successful litigant pay for the privilege of being right, that is the rule in Virginia. Throw in the fact that Virginia courts
strictly construe construction contracts and voila we have a situation where without a provision in the contract stating that one party or both will be able to collect attorney fees should that contractor or subcontractor prevail, a construction professional that gets sued (whether rightly or wrongly) will be left with a hefty attorney fees bill and no way to recoup those fees through the courts or any other method.
Read the full story...Reprinted courtesy of
The Law Office of Christopher G. HillMr. Hill may be contacted at
chrisghill@constructionlawva.com
White and Williams Recognizes Women’s History Month: Remembering Virginia Barton Wallace
April 08, 2024 —
White and Williams LLPMarch is Women’s History Month – a month dedicated to the accomplishments and history of women in the United States. The theme for
International Women’s Day, which is this Thursday March 7, is “Inspire Inclusion.” White and Williams LLP is dedicated to understanding, valuing and inspiring inclusion in the field of law
White and Williams is proud of the women who have become leaders in the firm’s history, starting with Virginia “Ginny” Barton Wallace, an extraordinarily accomplished pioneer among female attorneys. She joined the firm immediately after graduating from University of Pennsylvania School of Law in 1950, and in 1961, Ginny became the first woman to become the first female partner not only at White and Williams but also at any law firm in Philadelphia.
Read the full story...Reprinted courtesy of
White and Williams LLP
Real Estate & Construction News Roundup (1/10/24) – New Type of Nuclear Reactor, Big Money Surrounding Sports Stadiums, and Positivity from Fannie Mae’s Monthly Consumer Survey
February 05, 2024 —
Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law BlogIn our latest roundup, the commercial real estate market poses a risk to financial stability, New York City moves towards net-zero building emissions, workers at several Los Angeles area hotels tentatively agree to a new contract, and more!
Read the full story...Reprinted courtesy of
Pillsbury's Construction & Real Estate Law Team
Meet the Forum's In-House Counsel: RACHEL CLANCY
November 16, 2023 —
Jessica Knox - The Dispute ResolverCompany: Lobar, Inc.
Email: rachel.clancy@lobar.com
Website: www.lobar.com
College: York College of Pennsylvania (Bachelor of Science in Marketing, 2001)
Graduate School: Florida Institute of Technology (MBA in Acquisition and Contract Management, 2004)
Law School: Penn State University, Dickinson School of Law (JD 2007)
States Where Company Operates/Does Business: Headquarters are in Dillsburg, PA; construction projects located in Pennsylvania, Maryland, New York, and West Virginia
Q: Describe your background and the path you took to becoming in-house counsel.
A: Before law school, I spent three years as a Contract Specialist writing construction contracts for the Department of Defense, Naval Facilities Command in New Jersey. I had no idea I'd eventually find my way back to construction. After law school, I spent five years in the business department of a local law firm handling corporate formations, a variety of commercial contracts, and learning some real estate law. After another four years in-house with a data and marketing company in Harrisburg, I accepted my current position with Lobar, where I've been for the last seven years.
Read the full story...Reprinted courtesy of
Jessica Knox, Stinson LLPMs. Knox may be contacted at
jessica.knox@stinson.com
Understanding California’s Pure Comparative Negligence Law
November 13, 2023 —
Yaron Shaham - Kahana FeldIn order for a plaintiff to prove a defendant is negligent, the plaintiff must prove the defendant (1) owed a duty to plaintiff, (2) breached that duty, (3) the breach was the actual and proximate cause of plaintiff’s injury, and (4) the resulting monetary damage. However, for both plaintiffs and defendants it is not an all or nothing game in California. This is because California is a pure Comparative Negligence state.
California’s Comparative Negligence law provides that even if a plaintiff is deemed 99% at fault, the plaintiff can still recover 1% in damages from a defendant. Thus, even if a plaintiff is deemed to be more than 50% (or even 99%) at fault for the incident, the plaintiff could still recover some monetary amount, or the defendant will still have to pay plaintiff, depending on how you see it. In most instances, a jury decides what percentage of fault to assign to each party.
Just as a plaintiff must prove he/she/its negligence case against a defendant, if the defendant claims plaintiff was partially responsible for the incident, the defendant must prove plaintiff was also negligent and said negligence contributed to plaintiff’s injuries. The total amount of monetary responsibility distributed among all defendants and plaintiffs must equal 100%. As crazy as it may sound, a plaintiff found to be 99.9% at fault, is still entitled to recover 0.01% from a defendant in California.
Read the full story...Reprinted courtesy of
Yaron Shaham, Kahana FeldMr. Shaham may be contacted at
yshaham@kahanafeld.com