FAIRFIELD CONNECTICUT CONSTRUCTION EXPERT WITNESS
DIRECTORY AND CAPABILITIES

A “Flood” of Uncertainty; Massachusetts SJC Finds Policy Term Ambiguous

August 26, 2024 — Michael S. Levine & Torrye Zullo - Hunton Insurance Recovery Blog
The highest court in Massachusetts recently held that term “Flood” and the associated phrase “surface waters,” as used in two all-risk insurance policies, is ambiguous in the context of water that accumulated on a parapet roof and rooftop courtyard, thereby negating the insurers’ attempt to limit coverage to a sublimited coverage for “Flood.” Background In June 2020, a severe storm caused damage to Norwood Hospital, owned by Medical Properties Trust, Inc. (“MPT”) and leased to Steward Health Care System (“Steward”), the policyholders. The relevant portion of the damage included damage from rain that accumulated on the rooftop courtyard and seeped into the interior of the building causing damage to the building and its contents. Reprinted courtesy of Michael S. Levine, Hunton Andrews Kurth and Torrye Zullo, Hunton Andrews Kurth Mr. Levine may be contacted at mlevine@HuntonAK.com Ms. Zullo may be contacted at tzullo@HuntonAK.com Read the full story...

---

Newport Beach Attorneys John Toohey and Nick Rodriguez Receive Full Defense Verdict

July 31, 2024 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Bremer Whyte Brown & O’Meara is pleased to report that Partner John Toohey and Senior Associate Nicholas Rodriguez received a complete defense verdict after a 5-week jury trial in Orange County Superior Court. The case involved a multimillion-dollar home in Orange County. Plaintiff had originally suffered a water loss throughout areas of the home. Our client, an Orange County restoration and construction company, was hired to provide on-going estimates and perform demolition. Plaintiff claimed that, in the course of the demolition process, asbestos containing material was disturbed and spread resulting in contamination throughout home. Plaintiff claimed contractor negligence and breach of contract against our client. Plaintiff sought millions against our client in general and special damages for whole home restoration and other related general damages. The jury found in complete favor of our client on all allegations and awarded zero dollars to the opposing party. Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

---

Ensuing Loss Provision Salvages Coverage for Water Damage Claim

September 16, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The Court of Appeals for the D.C. Circuit reversed the district court's finding of no coverage and found that the ensuing loss provision provided coverage for water damage. 3524 East Cap Venture, LLC, et al. v. Weschester Fire Ins. Co., et al., 104 F. 4th 193 (D.C. Cir. 2024). Plaintiff 3534 East Cap Venture, LLC, a real-estate developer, hired plaintiff McCullough Construction, LLC, to build a residential and retail complex. Defendants Westchester Fire Insurance Company and Endurance American Insurance Company issued identical builders' risk policies, which covered the building while it was under construction. Each insurer was responsible for half of any qualifying losses. The policies covered loss caused by or resulting from water damage. The policies, however, excluded loss caused by "dampness of atmosphere" or by "[e]xtremes or changes in temperature." But the exclusions contained an exception if "loss by an insured peril ensues." Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

What Every Project Participant Needs to Know About Delay Claims

August 05, 2024 — Andrew G. Vicknair - The Dispute Resolver
A “delay” on a construction project is defined as the stretching out of the time for completion of certain key milestone scopes of work which can impact the completion date of an entire project, due to some circumstances or events that were not reasonably anticipated when the project began. 2 Construction Law ¶ 6.01 (Matthew Bender, 2024). While delays can be caused by any number of events, the most common are defective plans and specifications; design changes; severe weather and other, similar unforeseeable events; unforeseen or differing site conditions; unavailability of materials or labor; labor inefficiencies or stoppages; contractor negligence; and owner influences, including construction changes or outright interference by the owner or its agents. If the project schedule is not recovered following a delay, then the project schedule will likely be extended, resulting in an increase in the contractor’s costs of performance. A contractor that has experienced a delay on a project can take certain actions to pursue recovery of any damages the contractor may have incurred. However, to do so it is important to understand the different types of delays and the methods for establishing the delays. I. Types of Delays Delays may be categorized as (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. A critical delay is a delay that affects the project completion date and delays the entire project. In essence, a critical delay is one that will extend the critical path of a project. A non-critical delay is a delay that has no effect on the project’s critical path. Courts have recognized that delays to work not on the critical path will generally not delay the completion of a project. G.M. Shupe, Inc. v U.S., 5 Cl. Ct. 662, 728 (1984). Such a non-critical delay may affect the completion of certain activities, but does not affect the completion date of the entire project. In order for a delay to provide the basis for a claim for additional time or money, the delay must impact critical path activities on the project schedule. Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

---

Recovering Time and Costs from Hurricane Helene: Force Majeure Solutions for Contractors

November 18, 2024 — Matthew DeVries - Best Practices Construction Law
When Hurricane Helene struck North Carolina, it caused severe disruptions to construction projects across the state. Baxter International’s North Cove facility in Marion, N.C., was completely shut down after floodwaters damaged the site and bridges leading to it. Elsewhere, landslides and floods wiped out large sections of Interstate 40, making transportation of materials and equipment nearly impossible. Many contractors in western North Carolina found their projects halted, and their schedules thrown off by this force majeure event. In situations like these, contractors and subcontractor need a plan to mitigate the impact of such natural disasters on their projects. Here are five practical tips to help you secure time extensions and/or compensation for delays: 1. Include a Robust Force Majeure Clause in Your Contract When disaster strikes, your contract is your first line of defense. A well-drafted force majeure clause can make the difference between bearing the costs yourself and getting an extension or compensation. The clause should clearly list specific events such as hurricanes, floods, and road closures as qualifying force majeure events. Read the full story...
Reprinted courtesy of Matthew DeVries, Buchalter
Mr. DeVries may be contacted at mdevries@buchalter.com

---

Updates to AIA Contract Applications

January 07, 2025 — Anand Gupta - Construction Law Zone Blog
The construction industry often relies on contract forms drafted by the American Institute of Architects (AIA). These AIA forms include agreements between owners, designers, consultants, contractors, subcontractors, and construction managers. Some prefer to use the forms in the stock form, but others prefer to modify the language to their benefit. These modifications can be made in Microsoft Word and uploaded into AIA’s current web-based system, ACD5, to create redlines against the standard AIA forms (Checked-Drafts) and final clean versions without the “DRAFT” watermarks. Law firms and clients keep repositories of these modified templates for future projects. A common issue with modifying documents offline in Microsoft Word and passing the documents back-and-forth between different email and document management systems is that the metadata of the forms becomes corrupted. AIA technical support then must reset the metadata, which takes hours or days. This delay can pose challenges to clients when they are up against a deadline. Read the full story...
Reprinted courtesy of Anand Gupta, Robinson+Cole
Mr. Gupta may be contacted at agupta@rc.com

---

Kahana Feld LLP Senior Attorney Rachael Marvin and Partner Dominic Donato Obtain Complete Dismissal of Plaintiff’s Labor Law Claims on Summary Judgment

August 19, 2024 — Rachel Marvin - Kahana Feld
Kahana Feld attorneys Rachael Marvin and Dominic Donato secured summary judgment dismissal of plaintiff’s Labor Law §§ 240(1), 241(6), and 200 claims asserted against their client, a general contractor of a housing project in Orange County, New York. The case involved a construction accident in which plaintiff fell while traversing a ramp, which was placed across an eight-foot-deep excavation trench. Plaintiff was employed by a subcontractor and was part of a crew performing the framing work on the project. The accident occurred when he exited his work area by walking across a ramp that was placed across the excavated trench, when the ramp gave way and plaintiff fell into the excavation. Read the full story...
Reprinted courtesy of Rachel Marvin, Kahana Feld
Ms. Marvin may be contacted at rmarvin@kahanafeld.com

---

Contractor Suffolk's Hospital Project Is on Critical List After Steward Health Care Bankruptcy

January 14, 2025 — Richard Korman - Engineering News-Record
Before it was hit by troubles that now threaten to kill it, a new hospital being built by Suffolk Construction in Norwood, Mass., was shaping up as a tale of recovery. The existing hospital on the site had been forced to shut most local operations since a devastating rainfall and flood in 2020. Read the full story...
Reprinted courtesy of Richard Korman, ENR

---