FAIRFIELD CONNECTICUT CONSTRUCTION EXPERT WITNESS
DIRECTORY AND CAPABILITIES

Nine ACS Lawyers Recognized by Best Lawyers®

September 02, 2024 — Ahlers Cressman & Sleight PLLC
Departing from our blog’s typical coverage of construction related issues, Ahlers Cressman & Sleight PLLC is proud to announce that nine members of our firm have been recognized by Best Lawyers® in 2025 in America. Recognition by Best Lawyers® is based entirely on peer review and is designed to reflect the consensus opinion of leading lawyers about the professional abilities of their colleagues. Lawyers can be nominated by clients and other lawyers. After nomination, ballots are generated and distributed to lawyers. Voters are asked how likely they would be to refer a case to the nominee and to give a rating and additional comments. Ballots are designed based on the voter’s practice area and geographic region. After feedback is analyzed, Best Lawyers® research staff ensures nominees are in good standing with the ethics committee of their state bar and selects lawyers for recognition. Read the full story...
Reprinted courtesy of Ahlers Cressman & Sleight PLLC

---

Los Angeles Is Burning. But California’s Insurance Industry Is Not About to Collapse.

January 14, 2025 — Jerry Theodorou - R Street
Five fires are raging in the Los Angeles outskirts currently – the Palisades Fire, the Eaton Fire, the Lidia Fire, the Sunset Fire, and the Hurst Fire. They have been stoked by a trifecta of 100 mph wind gusts, elevated heat, and bone-dry grass and shrubs serving as tinder. The severity of the fires has raised questions about the role of climate change in the conflagrations and insurers’ claims-paying capacity. But while we recognize the immensity of the hardship and tragedy to many Angelenos from the fires, we also must recognize that California’s insurance industry is not about to collapse. Many have ignored or missed recent reforms to California insurance regulation that are poised to make the private market more sustainable, and help stem an exodus of insurers from the Golden State. Whether the intensity of wildfires is exacerbated by climate change is an open question. An R Street study found that natural catastrophes have increased in severity, but not in frequency. And the main reason catastrophe severity has risen is an increase in the built environment – there is simply more stuff now to be destroyed. Read the full story...
Reprinted courtesy of Jerry Theodorou, R Street
Mr. Theodorou may be contacted at jtheodorou@rstreet.org

---

What Every Project Participant Needs to Know About Delay Claims

August 05, 2024 — Andrew G. Vicknair - The Dispute Resolver
A “delay” on a construction project is defined as the stretching out of the time for completion of certain key milestone scopes of work which can impact the completion date of an entire project, due to some circumstances or events that were not reasonably anticipated when the project began. 2 Construction Law ¶ 6.01 (Matthew Bender, 2024). While delays can be caused by any number of events, the most common are defective plans and specifications; design changes; severe weather and other, similar unforeseeable events; unforeseen or differing site conditions; unavailability of materials or labor; labor inefficiencies or stoppages; contractor negligence; and owner influences, including construction changes or outright interference by the owner or its agents. If the project schedule is not recovered following a delay, then the project schedule will likely be extended, resulting in an increase in the contractor’s costs of performance. A contractor that has experienced a delay on a project can take certain actions to pursue recovery of any damages the contractor may have incurred. However, to do so it is important to understand the different types of delays and the methods for establishing the delays. I. Types of Delays Delays may be categorized as (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. A critical delay is a delay that affects the project completion date and delays the entire project. In essence, a critical delay is one that will extend the critical path of a project. A non-critical delay is a delay that has no effect on the project’s critical path. Courts have recognized that delays to work not on the critical path will generally not delay the completion of a project. G.M. Shupe, Inc. v U.S., 5 Cl. Ct. 662, 728 (1984). Such a non-critical delay may affect the completion of certain activities, but does not affect the completion date of the entire project. In order for a delay to provide the basis for a claim for additional time or money, the delay must impact critical path activities on the project schedule. Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

---

New York’s Highest Court Weighs in on N.Y. Labor Law

September 23, 2024 — Bill Wilson - Construction Law Zone
N.Y. Labor Law § 241(6) requires owners and contractors to provide reasonable and adequate protection and safety to persons employed at or lawfully frequenting a construction site. If a worker is injured on a construction site and establishes a violation of a specific and applicable Industrial Code regulation, both the owner and contractor will be held vicariously liable for the worker’s injury, without regard to their fault and even in the absence of control or supervision of the worksite. The Court of Appeals of New York recently addressed the broad scope of the Labor Law in the context of slipping hazards. In Bazdaric v. Almah Partners, LLC, 41 N.Y.3d 310 (2024), the plaintiff, an injured painter, slipped and fell on a plastic covering placed over an escalator in an area he was assigned to paint. The plaintiff claimed that the plastic covering was a foreign substance for purposes of Industrial Code 12 NYCRR 23-1.7(d) because it was not part of the escalator. Industrial Code 12 NYCRR 23-1.7(d) states:

Slipping hazards. Employers shall not suffer or permit any employee to use a floor, passageway, walkway, scaffold, platform or other elevated working surface which is in a slippery condition. Ice, snow, water, grease and any other foreign substance which may cause slippery footing shall be removed, sanded or covered to provide safe footing.

Read the full story...
Reprinted courtesy of Bill Wilson, Robinson & Cole LLP
Mr. Wilson may be contacted at wwilson@rc.com

---

Preserving Lien Rights on Private Projects in Washington: Three Common Mistakes to Avoid

September 16, 2024 — Kristina Southwell - Ahlers Cressman & Sleight PLLC
The Washington Construction Lien Statute, RCW 60.04 et seq., exists to help secure payment for work performed for the improvement of real property.[1] The statute grants “any person furnishing labor, professional services, materials, or equipment for the improvement of real property” the authority to claim “a lien upon the improvement for the contract price of labor, professional services, materials, or equipment furnished.” RCW 60.04.021. Exercising lien rights is one of the most useful tools available to a contractor or supplier trying to recover payment owed on a project. A properly recorded lien binds the project property, which is typically the most valuable asset held by the owner, as security for the amounts owed to the lien claimant. Additionally, the lien statute provides a basis for the claimant to recover the costs of recording the lien and its attorneys’ fees and expenses incurred in litigating the foreclosure of the lien. While the lien statute authorizes the right to lien, it also provides a series of strict requirements and procedures that a claimant must follow to properly exercise its rights. The claimant must carefully comply with all statutory requirements. This article does not endeavor to explain all the intricacies of the lien statute, but rather discusses three of the most common mistakes that result in the loss of lien rights. See our lien and bond claim manual for a more detailed guide to construction liens in Washington. Read the full story...
Reprinted courtesy of Kristina Southwell, Ahlers Cressman & Sleight PLLC
Ms. Southwell may be contacted at kristina.southwell@acslawyers.com

---

A Funny Thing Happened to My Ground Lease in Bankruptcy Court

November 25, 2024 — Christopher F. Graham & Morgan A. Goldstein - White and Williams LLP
EXECUTIVE SUMMARY Ground leases are an important – if somewhat unusual – part of the real estate finance industry. Because they typically cover large expensive properties like Rockefeller Center and The Empire State Building, to name two, and last a long time (99 years and up to start) the likelihood of something unexpected or unintended happening is high. This likelihood increases dramatically if, as highlighted below, one or both of the lease parties’ files for bankruptcy. Accordingly, real estate professionals should take note and take care when entering into any transaction involving a ground lease. Reprinted courtesy of Christopher F. Graham, White and Williams LLP and Morgan A. Goldstein, White and Williams LLP Mr. Graham may be contacted at grahamc@whiteandwilliams.com Ms. Goldstein may be contacted at goldsteinm@whiteandwilliams.com Read the full story...

---

Challenging a Termination for Default

September 23, 2024 — David Adelstein - Florida Construction Legal Updates
No contractor wants to be terminated for default. It is the harshest contractual recourse. It is a recourse that has implications, particularly in the public sector. However, a party needs to be in a position to support the basis of the termination for default, and the terminated party, in most instances, should not be in a position to imply accept the basis of the default. This applies regardless of the project. In the federal context: “When a contractor challenges a default termination, the government bears the burden of establishing the validity of the termination.” Sergent’s Mechanical Systems, Inc. v. U.S., 2024 WL 4048175, *7 (Fed.Cl. 2024) (internal quotation and citation omitted). Once the government establishes the default, “the contractor bears the burden of establishing that the default was excused by fault of the government.” Id. at *8 (internal quotation and citation omitted). Relevant considerations as to whether the contractor is in default include the contractor’s failure to meet contract specifications or the required schedule. Sergent’s Mechanical Systems, supra, at *8. “[T]here is ‘a requirement that the contractor give reasonable assurances of performance in response to a validly issued cure notice.” Id. (internal quotation and citation omitted). Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Supreme Court Eliminates Judicial 'Chevron' Deference to Federal Agency Statutory Interpretations

July 31, 2024 — Jane C. Luxton - Lewis Brisbois
Washington, D.C. (July 1, 2024) – In a much-anticipated decision, on June 28, 2024, the Supreme Court issued a sweeping opinion “overrul[ing]” a 40-year old precedent that required judges to defer to federal agency interpretations of their governing statutes when those laws were ambiguous or silent. Loper Bright Enterprises v. Raimondo, et al. No. 22-451 (2024), overruling Chevron U.S.A., Inc. v. Natural Resources Defense Council, Inc., 467 U.S. 837 (1984). The decision means that courts will no longer give special weight to an agency’s view of the scope of its regulatory powers but must apply independent judgment in deciding “whether an agency has acted within its statutory authority.” Loper Bright, slip op. at 35. Taking pains to explain that the new ruling would not allow for reversals of cases previously decided under the Chevron doctrine, the Court left no doubt that, in the words of Justice Neil Gorsuch, “[t]oday, the Court places a tombstone on Chevron no one can miss.” Id., Gorsuch Concurring Opinion at 1. Writing for a 6-2 majority, Chief Justice Roberts forcefully condemned the Chevron-based principle that courts should defer to a federal agency’s interpretation of the scope of its legal authority, rejecting the concept that agencies have any special expertise in statutory interpretation, a field reserved to the courts, not the executive branch, under Article III of the Constitution and the Administrative Procedure Act, 5 U.S.C. § 551 et seq. Read the full story...
Reprinted courtesy of Jane C. Luxton, Lewis Brisbois
Ms. Luxton may be contacted at Jane.Luxton@lewisbrisbois.com

---