Seattle Washington Construction Expert Witness Directory

There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense

October 01, 2024 — David Adelstein - Florida Construction Legal Updates
A federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!! In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:

The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.

Jackson Construction Co., supra, at 90.

Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Forum Selection Provisions Are Not to Be Overlooked…Even On Federal Projects

September 16, 2024 — David Adelstein - Florida Construction Legal Updates
Forum selection provisions are NOT to be overlooked. Ever. Treat them seriously. Even on federal projects where there is a Miller Act payment bond. Consider forum selection provisions on the front end when negotiating your contract. In a recent opinion, U.S. f/u/b/o Timberline Construction Group, LLC vs. Aptim Federal Services, LLC, 2024 WL 3597164 (M.D.Fla. 2024), a joint venture prime contractor was hired by the federal government to build a temporary housing site. The joint venture prime contractor obtained a Miller Act payment bond. The joint venture then entered into a subcontract with one of its joint venture members and the member-subcontractor then engaged a sub-subcontractor. The sub-subcontractor claimed it was owed $3.5 Million and sued the member-subcontractor, as well as the prime contractor’s Miller Act payment bond, in the Middle District of Florida. The member-subcontractor and the Miller Act payment bond sureties moved to transfer venue to the Middle District of Louisiana pursuant to a forum selection clause in the contract between the sub-subcontractor and the member-subcontractor. The contract provided that the exclusive venue would be a United States District Court located in Louisiana. Forum selection provisions are analyzed in federal court under 28 U.S.C. 1404(a): “For the convenience of parties and witnesses, in the interest of justice, a district court may transfer any civil action to any other district or division where it might have been brought or to any district or division to which all parties have consented.” U.S. f/u/b/o Timberline, supra at *2. A forum selection provision is presumptively valid and given controlling weight. Id. (quotations and citations omitted). Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Run Spot...Run!

November 18, 2024 — Daniel Lund III - Lexology
"The 'classic' definition of spot zoning is 'the process of singling out a small parcel of land for a use classification totally different from that of the surrounding area for the benefit of the owner of such property and to the detriment of other owners.’ Anderson’s American Law of Zoning, 4th Edition, § 5.12 (1995)” (from plannersweb.com). A wireless carrier rebuffed in Jennings, Louisiana, on an application to rezone residential property to site a monopole cell tower sought relief from the federal court for the Western District of Louisiana. The city lacked any wireless tower provisions in its ordinances, and the carrier asserted that existing “commercial property within the appropriate range” was unavailable. Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

Hawaii Supreme Court Reaffirms an "Accident" Includes Reckless Conduct, Finds Green House Gases are Pollutants

November 18, 2024 — Tred R. Eyerly - Insurance Law Hawaii
Answering certified questions from the federal district court, the Hawaii Supreme Court reaffirmed its prior holding that reckless conduct is an "occurrence' or accident. The court further held that green house gas (GHG) emissions were pollutants under liability policies. Aloha Petroleum, Ltd. v. National Union Fire Ins. Co. of Pittsburg, PA., et al., 2024 Haw. LEXIS 179 (Haw. Oct. 7, 2024). [Disclosure - our office was co-counsel on an amicus brief in this case filed on behalf of the United Policyholders]. The City and County of Honolulu and the County of Maui sued several fossil fuel companies, including Aloha Petroleum, Ltd., for climate change-related harms. The suits alleged that the fossil fuel industry knew beginning in the 1960s that its products would cause catastrophic climate change. Rather than mitigate their emissions, defendants concealed their knowledge of climate change, promoted climate science denial, and increased their production of fossil fuels. Defendants' actions, the complaints alleged, increased carbon emissions, which caused significant damage to the counties. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Executive Insights 2024: Leaders in Construction Law

August 05, 2024 — Construction Executive
The key risks that should always be taken into account when a contract is signed are risks associated with uncompensated delays and cost increases. Provisions relating to the scope of work deserve significant attention to help minimize these risks. Defining the scope of work is often put on the backburner while parties focus on negotiating the rest of the terms and conditions of the contract. And when these scopes are inserted, they are often not closely reviewed by attorneys who tend to defer to project personnel on scope. These situations can lead to costly disputes. Instead, make sure: (1) the correct plans and specifications have been referenced in the contract; (2) an attorney or his/her business counterpart is familiar with relevant specifications; (3) the exhibit containing the assumptions and clarifications is clearly written, has been coordinated with language in the body of the contract and can be clearly understood by attorneys and business people beyond the preconstruction personnel who drafted them; and (4) the contract addresses the order of precedence in the event of a conflict between or among contract provisions (including exhibits). With regard to specifications referenced above, an attorney review is advised because many specification sections, including submittal sections, change order sections, payment provisions and construction progress documentation sections, regularly vary from the negotiated sections of the actual contract. Contractors also unwittingly accept design risk through performance specifications, and the accompanying obligations and risks are underestimated by those tasked with the initial review of those documents. In sum, a clear scope is as important as clear terms and conditions. Reprinted courtesy of Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

Congratulations to Nicholas Rodriguez on His Promotion to Partner

November 25, 2024 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Bremer Whyte Brown & O’Meara, LLP is very proud to announce that Nick Rodriguez has been promoted to the position of partner with the firm! Nick has been with BWB&O since 2019 and is licensed to practice law in California and the U.S. District Courts. Nick’s practice focuses on complex construction defect matters, as well as personal injury and wrongful death claims. During his time with the firm, Nick has successfully represented numerous clients through alternative dispute resolution and has taken matters to trial where he has received favorable jury verdicts. He also supervises and manages a team of associates in the Newport Beach office. Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

Attorneys’ Fees and the American Arbitration Association Rule

September 09, 2024 — Bill Wilson - Construction Law Zone
A common question from clients, when a dispute arises on a construction project, is whether they can recover their attorney’s fees from the other side if they pursue a case and win. More often than not, such fees are not recoverable. As a general rule (commonly known as the “American Rule”), each party to a dispute must bear their own attorney’s fees unless there is some statutory provision or contractual agreement between the parties allowing otherwise. Since most construction disputes involve claims for breach of contract and/or negligence, no realistic statutory provision often allows for attorney’s fees. Many construction contracts do not typically provide a prevailing party the right to collect attorney’s fees from the other side. However, even if the American Rule applies, there may be another path to recovering attorney’s fees if the parties agree to arbitrate their dispute under the American Arbitration Association (AAA) rules. Reprinted courtesy of Bill Wilson, Robinson & Cole LLP Mr. Wilson may be contacted at wwilson@rc.com Read the full story...

Homeowner Survives Motion to Dismiss Depreciation Claims

September 23, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The insurer's motion to dismiss claims for improper claims handling when considering implementation of depreciation was denied. Morrison v. Indian Harbor Ins. Co, et al., 2024 U.S. Dist. LEXIS 115664 (S. D. W. Va. July 1, 2024). Plaintiff's home suffered flood damage. The house was insured by Indian Harbor a surplus lines carrier that offered specialized and high risk property policies in West Virginia. Surplus lines policies were procured in West Virginia through a "surplus lines licensee." Here, Neptune Flood Inc. was the surplus lines licensee broker for Indian Harbor. Peninsula Insurance Bureau, Inc. was an administrator and loss adjuster involved in the claim. After the flood, Plaintiff notified defendants of the damage and immediately cleaned and repaired the house. Plaintiff asserted that Neptune was given notice of the loss and one of its agents made recommendations regarding the coverage available and conveyed the information to Peninsula and Indian Harbour. Plaintiff claimed that defendants misrepresented his policy coverage and made incorrect adjustments for depreciation based on Neptune's statements and recommendations. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

SEATTLE WASHINGTON CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES