FAIRFIELD CONNECTICUT CONSTRUCTION EXPERT WITNESS
DIRECTORY AND CAPABILITIES

Five Issues to Consider in Government Contracting (Or Any Contracting!)

September 02, 2024 — David Adelstein - Florida Construction Legal Updates
The appeal of Appeals of – Konecranes Nuclear Equipment & Services, LLC, ASBCA 62797, 2024 WL 2698011 (May 7, 2024) raises interesting, but important, issues that should be considered. In this case, the government (in a supply contract) procured four portal cranes from the claimant. After an initial test of one of the cranes failed, the government refused to accept delivery even after the issue was addressed by the claimant. The government did not accept the manner in which the claimant addressed the issue and would only accept cranes if the claimant employed “an unnecessary alternative solution [that] caused further delay and increased [claimant’s] costs.” On appeal, it was determined the government’s decision to delay delivery based on its demand for the alternative solution was not justified, i.e., constituted a breach of contract. Below are five issues of consideration in government contracting, or, for that matter, any contracting. Issue #1- Patently Ambiguous Specifications The government argued that the specifications were patently ambiguous and because the claimant failed to inquire regarding the ambiguous specifications prior to performance, its interpretation of the ambiguous specifications should govern. The contractor countered that the specifications were unambiguous and it met the specifications. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Understanding Entitlement to Delays and Proper Support

December 10, 2024 — Andrew G. Vicknair - The Dispute Resolver
In a previous post, we discussed delays on construction projects including (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. We also reviewed the common methods of delay analysis include (1) the Total Cost Method, (2) the Modified Total Cost Approach, and (3) the Measured Mile Method. Once you have determined the type of delay and the method to be used to analyze and quantify the delay, it is important to understand the type of documents/evidence needed to support your claim for delay. If a party determines that they are entitled to some type of recovery for the delay, the party making a claim for delay, such as a contractor, must have the proper documentation/evidence to assist in proving entitlement for damages from the delay. Without the proper back-up, contractors are generally unable to recover all of the additional costs and expenses associated with the delays or, at best, recover only an “equitable” amount. Generally, damages must be proved with reasonable certainty and may not be based on speculation or conjecture. Thus, it is crucial for a party asserting a delay to have the proper documentation to support a delay claim, if the goal is to recover the damages associated with the delay. Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

---

Why Being Climate ‘Positive’ Is the Buzzy New Goal of Green Building

December 10, 2024 — Olivia Rudgard - Bloomberg
The three buildings, dotted around Norway, couldn’t look more different: a soaring timber-and-concrete obelisk in Porsgrunn; a squat, two-story Montessori school on the edge of a forest in Drøbak; and a concrete and glass wedge-shaped office in Trondheim, just a few hundred miles from the edge of the Arctic Circle. But they share a distinctive feature. Each has a roof perfectly tilted to squeeze out every possible drop of solar energy. They are called Powerhouses, and the initiative behind them claims they are all “energy positive”: The upfront energy “cost” of each building, and that of later demolition and disposal, is expected to be made back over the building’s lifetime. Powerhouses sometimes draw from the grid, especially in winter, but in the long Nordic summer days they give back many times over, overspilling excess solar energy into surrounding homes and businesses. Read the full story...
Reprinted courtesy of Olivia Rudgard, Bloomberg

---

Toolbox Talk Series Recap - The Mediator's Proposal

January 21, 2025 — Douglas J. Mackin - The Dispute Resolver
In our final edition of the year of Division 1's Toolbox Talk Series on December 19, 2024, Matthew Argue and Gene Witkin discussed the use of the Mediator’s Proposal to bridge any final gaps to settlement between parties to a mediation. For those unfamiliar, a Mediator’s Proposal is a settlement proposal that the mediator makes to all parties to the dispute simultaneously. Each party then advises the mediators in confidence whether they accept or reject the proposal. The Mediator will communicate to all the parties that the Mediator’s Proposal is accepted only if all parties accept. Argue and Witkin emphasized that the Mediator’s Proposal is not a shortcut and should not be used simply to split the difference. Instead, it is a tool available to the mediator to push the parties to resolution after they have had robust negotiations, understand the strengths and weaknesses of the positions of each side, and have made progress towards at least getting within range of one another. A successful Mediator’s Proposal depends on the mediator (and the parties) having sufficient information to make a credible recommendation and creating an environment where all parties will consider the Mediator’s Proposal in good faith. Read the full story...
Reprinted courtesy of Douglas J. Mackin, Cozen O’Connor
Mr. Mackin may be contacted at dmackin@cozen.com

---

Top 10 Take-Aways from the 2024 Fall Forum Meeting in Pittsburgh

December 03, 2024 — Marissa L. Downs - The Dispute Resolver
Over 500 construction law attorneys and consultants convened last week at the confluence of three rivers in what became the first-ever meeting in Pittsburgh, Pennsylvania of the ABA Forum on Construction Law. The Steel City was a fitting backdrop for a meeting focused on issues of design in construction. Thanks to the hard work of many, most notably the newly minted Forum Chair Keith Bergeron and Meeting Coordinators Kendall Woods and Michael Clark, the meeting's attendees brought home new connections and a host of new lessons learned. Read on for my top 10 take-aways from the 2024 Fall Meeting in Pittsburgh and feel free to share yours in the comments below. 10. An architect's standard of care does not require perfection. A common refrain across many of the meeting's plenary sessions was that any design that is produced by human hands will never be perfect. In recognition of our own fallibility, the legal standard to which design professionals will be held to account does not require that their designs be error-free. A design professional must generally exercise the degree of care and skill ordinarily exercised by professionals performing similar services under similar circumstances. Establishing what that means in each locality will vary and will most likely need to be supported by the expert opinion of another practicing design professional. Read the full story...
Reprinted courtesy of Marissa L. Downs, Laurie & Brennan, LLP
Ms. Downs may be contacted at mdowns@lauriebrennan.com

---

Real Estate & Construction News Roundup (7/17/24) – Housing Inflation to Remain High, Proptech Investment to Fall and Office Vacancy Rates to Reach Peak in 2025

August 26, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, construction backlog to see positives signs, regional banks to be conservative on buybacks, U.S. metro areas to permit few new housing units, and more!

• Venture capital investments in proptech and adjacent companies fell 14.3% in the first half of the year. (Leslie Shaver, Multifamily Dive)
• The expectation of interest rate cuts by the Federal Reserve later this year due to easing inflation and cooling economic growth is a positive sign for construction backlog. (Sebastian Obando, Construction Dive)
• The U.S. office real estate sector is now in three markets, each with different performance, but the overall office vacancy rate will reach a 21.6% peak in the second half of 2025. (Nish Amarnath, Construction Dive)

Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

---

ASCE Statement on Hurricane Milton and Environmental Threats

October 15, 2024 — Feniosky Peña-Mora, P.E., President - American Society of Civil Engineers
WASHINGTON, DC. – On the heels of the tragic damage caused by Hurricane Helene throughout the Southeast, Floridians were struck by another major hurricane, Milton, less than two weeks later. Our hearts go out to those impacted again by this storm through property damage, lack of water access, power outages, or worse, loss of life, all before getting a chance to recover from Helene. Civil engineers are dedicated to protecting the public with projects that can lessen the impacts of these storms, and we are eager to help communities rebuild as quickly as possible following events like Milton and Helene. Although we do not yet know the full scope of destruction caused by Hurricane Milton, severe weather, including compound flooding events, are increasing regularly and pose a great risk to our safety and economic vitality. While so many eyes are fixated on hurricanes impacting the Southeast, wildfires are burning across several western states, including the Elk Fire in Wyoming, the largest wildfire the Bighorn National Forest has experienced in more than a century, now spanning over 75,000 acres as the region is experiencing unusually hot and dry weather and strong winds that are helping this fire to spread rapidly. The climate impacts we are accustomed to – wildfires in the West and hurricanes in the Southeast – are getting stronger, and now environmental challenges are occurring in areas we wouldn't suspect, such as Hurricane Helene striking mountain communities in Western North Carolina that have been labeled as "climate safe-havens," and Texas dealing with annual winter storms. ASCE is a leader in codes and standards development and has created an easy-to-understand toolkit for legislators and the public to learn the benefits of these up-to-date standards and determine when and how to adopt them, making our built environment more resilient to natural catastrophes. ASCE's flagship standard, ASCE/SEI 7-22, recently underwent the most significant update to its flooding chapter to ensure structures following this standard are prepared for 500-year flood events.

---

A Chicago Skyscraper Cements the Legacy of a Visionary Postmodern Architect

December 31, 2024 — Mark Byrnes - Bloomberg
A handsome and eclectic stretch of buildings along Michigan Avenue known as “Chicago’s Front Door” offers a view that reflects the city’s status as a destination for serious architecture. Louis Sullivan and Dankmar Adler’s Auditorium Building, where a young Frank Lloyd Wright designed interiors, is right there on Grant Park; so is Daniel Burnham’s Railway Exchange, where he drew up the 1909 Plan of Chicago. Now a glass-and-aluminum apartment tower anchors the southern end of this scene, filling in a rare gap within this landmarked streetwall and putting a bow on the career of another heroic figure in Chicago’s architectural history: Helmut Jahn. Read the full story...
Reprinted courtesy of Mark Byrnes, Bloomberg

---