COLUMBUS OHIO CONSTRUCTION EXPERT WITNESS
DIRECTORY AND CAPABILITIES

Second Circuit Affirms Win for General Contractor on No Damages for Delay Provision

September 02, 2024 — Bill Wilson - Construction Law Zone
In NASDI, LLC v. Skanska Koch Inc. Kiewit Infrastructure Co. (JV), 2024 WL 1270188 (2d Cir. Mar. 26, 2024), the U.S. Court of Appeals for the Second Circuit affirmed the District Court’s grant of summary judgment dismissing a subcontractor’s delay claim against a general contractor on a public project in New York state. The Court enforced a typical no-damages-for-delay provision to bar the subcontractor’s breach of contract claim. The no-damages-for-delay provision in the subcontract at issue provided:

NO DAMAGE FOR DELAY. Except as otherwise provided …, Subcontractor agrees that it shall have no Claim against Contractor for any loss or damage it may sustain through delay, disruption, suspension, stoppage, interference, interruption, compression, or acceleration of Subcontractor’s Work (‘Delay Damages’) caused or directed by Contractor for any reason, and that all such Claims shall be fully compensated for by Contractor’s granting Subcontractor such time extensions as it is entitled to as a result of any of the foregoing.

Read the full story...
Reprinted courtesy of Bill Wilson, Robinson & Cole LLP
Mr. Wilson may be contacted at wwilson@rc.com

---

Benefit of the Coblentz Agreement and Consent Judgment

August 26, 2024 — David Adelstein - Florida Construction Legal Updates
If you are not familiar with the concept of what is commonly known as a Coblentz agreement relative to an insurance coverage dispute, review these prior postings (here and here and here). This is a good-to-know agreement if you are a claimant and need to consider an avenue of collection if the insured’s carrier denies coverage out of the gate (meaning the carrier has denied both the duty to defend and the duty to indemnify). A recent Eleventh Circuit Court of Appeals opinion demonstrates the Coblentz agreement concept. In Barrs v. Auto-Owners Ins. Co., 2024 WL 3673089 (11th Cir. 2024), an owner asserted a construction defect claim against its contractor. The owner hired the contractor to deconstruct a building and the contractor hired a demolition subcontractor. The owner noticed work was not being performed and materials (e.g., lumber) were missing; the demolition subcontractor had stolen materials. The subcontractor was terminated, and the owner claimed the contractor’s negligence allowed the theft and delayed his project. The contractor’s commercial general liability (CGL) insurer notified the insured-contractor that coverage did not exist and refused to defend the contractor. The owner sued the contractor under various theories of liability. The owner and contractor entered into a settlement agreement (i.e., the Coblentz agreement) where the contractor “admitted liability in the amount of $557,500.00….A consent judgment was entered against [the contractor] that closely tracked the settlement agreement but did not indicate which portion of the damages award was attributed to which claims. The agreement also assigned [owner] and all of [the contractor’s] rights to claim coverage and to recover available funds under [the contractor’s CGL policy].” Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Surprising Dismissal of False Claims Act Case Based on Appointments Clause - What Does It Mean?

October 15, 2024 — Steven H. Lee - Lewis Brisbois Newsroom
Atlanta, Ga. (October 1, 2024) - In a surprising turn of events, the U.S. District Court for the Middle District of Florida recently dismissed a False Claims Act (FCA) lawsuit brought by relator Clarissa Zafirov against Florida Medical Associates, LLC, and other defendants. U.S. District Judge Kathryn Kimball Mizelle ruled that the FCA’s qui tam provisions, which allow private individuals to bring lawsuits on behalf of the government, violate the Constitution’s Appointments Clause. This decision follows another unexpected ruling by U.S. District Judge Aileen Cannon in the Southern District of Florida, where the court similarly dismissed an indictment against former President Donald Trump based on the same constitutional clause. At the heart of these rulings is the argument that FCA relators - who decide whom to sue, which legal theories to pursue, and how to proceed - exercise significant executive authority. Because they are not appointed by the President, a department head, or a court, the judges concluded that these relators hold their positions unconstitutionally. As a result, Judge Mizelle dismissed the case entirely. Read the full story...
Reprinted courtesy of Steven H. Lee, Lewis Brisbois
Mr. Lee may be contacted at Steven.Lee@lewisbrisbois.com

---

$31.5M Settlement Reached in Contract Dispute between Judlau and the Illinois Tollway

September 16, 2024 — Annemarie Mannion - Engineering News-Record
The Illinois Tollway will pay nearly $31.5 million to New York-based Judlau Contracting and its trade contractors to resolve a lawsuit filed after the tollway, in April, terminated a $324-million contract with Judlau to rebuild the southbound lanes of the Interstate 290 and Interstate 88 interchange near Oak Brook, Ill. Reprinted courtesy of Annemarie Mannion, Engineering News-Record Ms. Mannion may be contacted at manniona@enr.com Read the full story...

---

Untangling Unique Legal Issues in Modern Modular Construction

September 09, 2024 — Chad Theriot & Brad Sands - Construction Executive
Modular construction has grown significantly over the last few years and shows no signs of slowing down. This construction method is a departure from traditional approaches where all construction activity occurs onsite. Modular construction involves building standardized project components—usually in an offsite, controlled environment—which are then transported and assembled at the project site. Offsite construction generally allows for better quality control and economic efficiency, as it can utilize an assembly-line process. Modular fabrication can also centralize skilled labor in regions with lower labor costs. Establishing each party's expectations upfront is always important, but even more so in modular construction since much of the construction activity is performed away from the ultimate project site. This requires extensive coordination among designers, fabricators, installers and owners to ensure construction, testing and quality progresses accordingly. Every field change and design clash could have an exponential impact on the modular fabrication efficiencies given the assembly-line approach and remote nature of modular work. Reprinted courtesy of Chad Theriot & Brad Sands, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

---

Rhode Island Sues 13 Industry Firms Over Flawed Interstate Bridge

September 23, 2024 — Richard Korman - Engineering News-Record
In an attempt to recoup any money Rhode Island will owe to others for rerouting traffic on half of a high-volume interstate bridge in Providence after structural flaws had been detected, the state Dept. of Transportation filed a lawsuit Aug. 16 against 13 engineers and contractors that had inspected or performed work on the Washington Bridge in the last decade. Reprinted courtesy of Richard Korman, Engineering News-Record Mr. Korman may be contacted at kormanr@enr.com Read the full story...

---

Julie Firestone & Francois Ecclesiaste Recognized as 2023 MSBA North Star Lawyers

July 15, 2024 — Lewis Brisbois Newsroom
Minneapolis, Minn. (June 11, 2024) - Minneapolis Partners Julie Firestone and Francois Ecclesiaste were recently named to the Minnesota State Bar Association (MSBA) 2023 North Star Lawyers list, which recognizes attorneys who provide pro bono service to people of low income at no fee. All attorneys who were recognized by MSBA provided 50 hours or more of pro bono service to low-income Minnesotans last year. MSBA has a long-standing dedication to advancing the Bars’ pro bono efforts through training, recruiting, and sharing pro bono stories in the community. “Lewis Brisbois has a long-standing commitment to serving our local communities, including through our pro bono practice, and we are proud of our partners who exemplify this core value of our Firm,” expressed Michelle Gilboe, Managing Partner of the Minneapolis office. Read the full story...
Reprinted courtesy of Lewis Brisbois

---

Toolbox Talk Series Recap - Guided Choice Mediation

November 05, 2024 — Douglas J. Mackin - The Dispute Resolver
In the September 26, 2024 edition of Division 1's Toolbox Talk Series, Clifford Shapiro presented on Guided Choice Mediation (“GCM”) and how it can lead to better outcomes in construction disputes. GCM is an approach to mediation that focuses on early and efficient dispute resolution, which prominent mediators created as a public interest project. Shapiro described his particular variant of GCM based on his experience while acknowledging that other Guided Choice Mediators’ processes may differ from his in various ways. Shapiro’s brand of GCM focuses on ensuring that parties have reasonable expectations and appropriate settlement authority prior to arriving at a mediation. Some of the strategies to help accomplish these noble goals are (i) early mediator engagement, (ii) mediator facilitation of information exchange, (iii) mediator involvement with insurance issues (particularly important in construction defect cases, especially those with multiple defendants), (iii) pre-mediation ex parte meetings, and (iv) mediator participation in risk analysis. These strategies are not typical in the more traditional/historic approach to mediation in which mediation is scheduled based on a scheduling order, mediation statements are sent to the mediator roughly a week before the scheduled mediation (and sometimes not even shared with anyone other than the mediator), and the parties speak with the mediator for the first time on the day of the mediation. Read the full story...
Reprinted courtesy of Douglas J. Mackin, Cozen O’Connor
Mr. Mackin may be contacted at dmackin@cozen.com

---