Fairfield Connecticut Construction Expert Witness Directory

Understanding Entitlement to Delays and Proper Support

December 10, 2024 — Andrew G. Vicknair - The Dispute Resolver
In a previous post, we discussed delays on construction projects including (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. We also reviewed the common methods of delay analysis include (1) the Total Cost Method, (2) the Modified Total Cost Approach, and (3) the Measured Mile Method. Once you have determined the type of delay and the method to be used to analyze and quantify the delay, it is important to understand the type of documents/evidence needed to support your claim for delay. If a party determines that they are entitled to some type of recovery for the delay, the party making a claim for delay, such as a contractor, must have the proper documentation/evidence to assist in proving entitlement for damages from the delay. Without the proper back-up, contractors are generally unable to recover all of the additional costs and expenses associated with the delays or, at best, recover only an “equitable” amount. Generally, damages must be proved with reasonable certainty and may not be based on speculation or conjecture. Thus, it is crucial for a party asserting a delay to have the proper documentation to support a delay claim, if the goal is to recover the damages associated with the delay. Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

What You Need to Know to Protect the Project Against Defect Claims

October 28, 2024 — Scott L. Baker - Los Angeles Litigation Blog
If a property owner claims there is a construction defect, that not only brings the project’s integrity into question but also your business’s reputation. So, how can you take steps to prevent these claims from causing such damage? Here are three things to know before beginning a project to effectively protect it and manage construction defect claims. 1. Documentation is key California and Los Angeles County require certain permits and documents in order for a construction project to move forward. Los Angeles County will also conduct plan checks to ensure everything is up to code. Detailed documentation will be important while making your plans. However, keeping notes throughout every step of the project will also be essential. Documenting all aspects of the project helps you:

Stay updated and aware of the project’s progress
Proactively catch and handle issues that could result in disputes
Create a record of evidence that can help manage defect claims

Read the full story...
Reprinted courtesy of Scott L. Baker, Baker & Associates
Mr. Baker may be contacted at slb@bakerslaw.com

Construction Litigation Roundup: “Give a Little Extra …”

July 31, 2024 — Daniel Lund III - Lexology
Surplus lines insurers in Louisiana are considered by the state to be “an alternative type of property and casualty insurance coverage for consumers who cannot get coverage on the standard market … for specialty risk or high-risk situations….” As a quid pro quo for undertaking the exceptional risk, a surplus lines insurer argued to the United States Fifth Circuit Court of Appeals that an arbitration clause within its surplus line policy should be enforceable, notwithstanding a Louisiana statute applying to the insurance industry and prohibiting terms in insurance policies “delivered or issued for delivery” in Louisiana which have the effect of “[d]epriving the courts of this state of the jurisdiction or venue of action against the insurer.” La. R.S. 22:868. Historically in Louisiana, arbitration clauses have been understood to divest courts of jurisdiction, and, consequently, §22:868 has been held to memorialize an “anti-arbitration policy,” although the statute does not specifically mention arbitration. Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

GRSM Attorneys Selected to 2024 Super Lawyers and Rising Stars Lists

January 14, 2025 — Gordon Rees Scully Mansukhani
Super Lawyers® has released its 2024 attorney lists across various regions of the United States. This year, 169 Gordon Rees Scully Mansukhani attorneys have been selected, with 51 named to Super Lawyers and 118 named to Rising Stars. *For attorneys licensed to practice in New Jersey: No aspect of this advertisement has been approved by the Supreme Court of New Jersey. Please visit the Super Lawyers Selection Process for a detailed description of the Super Lawyers and Rising Stars selection methodology. The selections are a result of independent research by the team at Super Lawyers® to determine no more than the top five percent of legal professionals in each geographic region. The research team selects no more than two and a half percent of the lawyers in each geographic region to the Rising Stars list. Read the full story...
Reprinted courtesy of Gordon Rees Scully Mansukhani

Top 10 Insurance Cases of 2024

January 21, 2025 — Jeffrey J. Vita & Michelle A. Grieco - Saxe Doernberger & Vita, P.C.
Federal and state courts tackled a myriad of interesting insurance-related issues this past year. The U.S. Supreme Court also surprisingly addressed coverage issues in 2024, in not one—but two—decisions. It is rare for the Supreme Court to confront insurance coverage issues which usually involve matters of state law. The highest court’s assessment of the nuances of insurance to resolve maritime choice of law issues and interpret an insurer’s role in bankruptcy proceedings is indicative of the significant role that insurance coverage plays in resolving commercial disputes. Additionally, 2024 included a pivotal opinion from the 5th Circuit, which welcomed the principle that negligent construction can constitute “property damage” under a CGL policy if it causes a harmful change to the property. Elsewhere in the country, the Hawaii Supreme Court ruled that reckless conduct can qualify as an “accident” under a CGL policy’s definition of “occurrence”; however, the court simultaneously ruled that greenhouse gases fall within the scope of “pollutants” under the policy’s pollution exclusion. Cyber coverage decisions were also prominent, and the 5th Circuit chimed in with an interesting decision interpreting the scope of coverage afforded under a “system failure” provision. These decisions represent a mere sampling of the multitude of insurance issues courts nationwide have grappled with in 2024. Reprinted courtesy of Jeffrey J. Vita, Saxe Doernberger & Vita, P.C. and Michelle A. Grieco, Saxe Doernberger & Vita, P.C. Mr. Vita may be contacted at JVita@sdvlaw.com Ms. Grieco may be contacted at MGrieco@sdvlaw.com Read the full story...

Kahana Feld Partner Noelle Natoli Named President of Women Lawyers Association of Los Angeles

October 07, 2024 — Linda Carter - Kahana Feld
LOS ANGELES – Sep. 16, 2024 – Kahana Feld is pleased to announce that partner Noelle Natoli was recently installed as the 2024-25 president of the Women Lawyers Association of Los Angeles (WLALA). The mission of WLALA is to promote the full participation in the legal profession of women lawyers and judges from diverse perspectives and backgrounds, maintain the integrity of our legal system by advocating principles of fairness and equality, and improve the status of women by supporting their exercise of equal rights. Natoli is a partner based in Kahana Feld’s Los Angeles office and focuses her civil trial practice on the defense of both insurers and insureds primarily in the areas of elder abuse, transportation defense, and general liability. Her clients include individuals, family-owned businesses, and national corporations. Natoli also chairs the Diversity & Inclusion Committee for the Trucking Industry Defense Association and serves as a board member of the National Conference of Women’s Bar Associations. Read the full story...
Reprinted courtesy of Linda Carter, Kahana Feld
Ms. Carter may be contacted at lcarter@kahanafeld.com

EPA Looks to Reduce Embodied Carbon in Materials With $160M in Grants

August 19, 2024 — James Leggate - Engineering News-Record
The U.S. Environmental Protection Agency estimates that construction materials used for buildings and built infrastructure account for more than 15% of global greenhouse gas emissions. The agency now hopes to boost adoption of materials with lower embodied emissions by offering $160 million in grants to better track and ultimately reduce climate pollution associated with those materials. Reprinted courtesy of James Leggate, Engineering News-Record Mr. Leggate may be contacted at leggatej@enr.com Read the full story...

Traub Lieberman Attorneys Lisa M. Rolle and Justyn Verzillo Win Motion for Summary Judgment

December 23, 2024 — Lisa M. Rolle & Justyn Verzillo - Traub Lieberman
In this subrogation action brought in the Supreme Court of the State of New York, Dutchess County, Traub Lieberman attorneys Lisa M. Rolle and Justyn Verzillo successfully obtained dismissal of a third-party complaint against their client, a fire-system protection company. In the underlying case, a fire sprinkler system within a commercial building leaked water into multiple tenant spaces, causing damage. The tenants’ insurers alleged that they each paid several hundred thousand dollars to cover their insureds’ claims. The insurers then filed complaints against the company which originally installed the sprinkler (the “Installer”), asserting that the company breached its duty of care. The Installer commenced a third-party action against the property owner and two fire-system protection companies—including Traub Lieberman’s client—who had separately conducted annual inspections of the sprinkler system over the years. The property owner and the two fire-system protection companies each asserted cross-claims against each other. Reprinted courtesy of Lisa M. Rolle, Traub Lieberman and Justyn Verzillo, Traub Lieberman Ms. Rolle may be contacted at lrolle@tlsslaw.com Mr. Verzillo may be contacted at jverzillo@tlsslaw.com Read the full story...

FAIRFIELD CONNECTICUT CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES