Columbus Ohio Construction Expert Witness Directory

Second Circuit Affirms Win for General Contractor on No Damages for Delay Provision

September 02, 2024 — Bill Wilson - Construction Law Zone
In NASDI, LLC v. Skanska Koch Inc. Kiewit Infrastructure Co. (JV), 2024 WL 1270188 (2d Cir. Mar. 26, 2024), the U.S. Court of Appeals for the Second Circuit affirmed the District Court’s grant of summary judgment dismissing a subcontractor’s delay claim against a general contractor on a public project in New York state. The Court enforced a typical no-damages-for-delay provision to bar the subcontractor’s breach of contract claim. The no-damages-for-delay provision in the subcontract at issue provided:

NO DAMAGE FOR DELAY. Except as otherwise provided …, Subcontractor agrees that it shall have no Claim against Contractor for any loss or damage it may sustain through delay, disruption, suspension, stoppage, interference, interruption, compression, or acceleration of Subcontractor’s Work (‘Delay Damages’) caused or directed by Contractor for any reason, and that all such Claims shall be fully compensated for by Contractor’s granting Subcontractor such time extensions as it is entitled to as a result of any of the foregoing.

Read the full story...
Reprinted courtesy of Bill Wilson, Robinson & Cole LLP
Mr. Wilson may be contacted at wwilson@rc.com

Arizona Court Affirms Homeowners’ Association’s Right to Sue Over Construction Defects

October 15, 2024 — Melissa Kenney - White and Williams LLP
In Gallery Community Association v. K. Hovnanian at Gallery LLC, No. 1 CA-CV 23-0375, 2024 Ariz. App. Unpub. LEXIS 696 (Ct. App.), the Court of Appeals of Arizona (Court of Appeals) discussed whether a homeowners’ association can file an action for breach of the implied warranty of workmanship and habitability arising from construction defects. At issue was whether the implied warranty extended to the areas within the community that the association maintained, including the common areas. The Court of Appeals held that homeowners’ associations can sue builder-vendors for breach of the implied warranty arising from construction defects. In this case, a homeowners’ association, responsible for managing and maintaining a community of townhomes, sued the developer/builder for alleged construction defects in the common area and exteriors of homes that the association maintained for the homeowners in the community. The alleged defects included the pool cabana and staircase walls in the common areas and the exterior walls, roofs, and staircases on the separately owned townhomes in the community. The builder filed a motion for summary judgment, arguing that the implied warranty extended to dwelling actions initiated by homeowners – not homeowners’ associations – and that the alleged construction defects at issue were not related to a dwelling. The trial court granted the motion. The Court of Appeals vacated the trial court’s grant of summary judgment and remanded for further proceedings. In reaching its decision, the Court of Appeals determined that both common law and statutory law authorized the homeowners’ association’s breach of implied warranty claim. Read the full story...
Reprinted courtesy of Melissa Kenney, White and Williams
Ms. Kenney may be contacted at kenneyme@whiteandwilliams.com

Homeowner Survives Motion to Dismiss Depreciation Claims

September 23, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The insurer's motion to dismiss claims for improper claims handling when considering implementation of depreciation was denied. Morrison v. Indian Harbor Ins. Co, et al., 2024 U.S. Dist. LEXIS 115664 (S. D. W. Va. July 1, 2024). Plaintiff's home suffered flood damage. The house was insured by Indian Harbor a surplus lines carrier that offered specialized and high risk property policies in West Virginia. Surplus lines policies were procured in West Virginia through a "surplus lines licensee." Here, Neptune Flood Inc. was the surplus lines licensee broker for Indian Harbor. Peninsula Insurance Bureau, Inc. was an administrator and loss adjuster involved in the claim. After the flood, Plaintiff notified defendants of the damage and immediately cleaned and repaired the house. Plaintiff asserted that Neptune was given notice of the loss and one of its agents made recommendations regarding the coverage available and conveyed the information to Peninsula and Indian Harbour. Plaintiff claimed that defendants misrepresented his policy coverage and made incorrect adjustments for depreciation based on Neptune's statements and recommendations. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Deterioration of Bridge Infrastructure Is Increasing Insurance Needs

December 03, 2024 — Grace Calengor - Construction Executive
As the world is taken by storm—literally, with increasing hurricanes, tornadoes, wildfires and more—insuring construction projects and infrastructure is becoming more complicated yet more necessary. Sean Pender, senior vice president of construction and development at CAC Specialty, is a leading specialty insurance broker and advisor. As major-storm season for the Northern hemisphere rounds out, he speaks with Construction Executive about the potential risk and insurance implications to the process of ensuring proper repairs, replacements and other forms of maintenance to one of the country’s most pivotal pieces of infrastructure: bridges. What does insurance coverage look like for building bridges in various environments throughout the country? Insurance is essential to protect the entity that owns the bridge during construction. Bridges under construction are at the highest risk of collapse because they are not yet fully stabilized and are exposed to severe weather and natural disasters, which could cause significant damage to the structure or injury to workers and civilians. Therefore, comprehensive liability insurance programs—typically with coverage limits of $50 to $100 million or higher—are crucial, especially with activities on or over waterways. Reprinted courtesy of Grace Calengor, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

Takeaways From Schedule-Based Dispute Between General Contractor and Subcontractor

September 09, 2024 — David Adelstein - Florida Construction Legal Updates
A recent opinion out of the Southern District of Florida, Berkley Insurance Co. v. Suffolk Construction Co., Case 1:19-cv-23059-KMW (S.D.Fla. July 22, 2024), provides valuable takeaways on schedule-based disputes between a general contractor and subcontractor on a high-rise project. In a nutshell, the general contractor’s original project schedule was abandoned due to project delays and the project wasn’t being built by any updated project schedule. The subcontractor claimed the general contractor was mismanaging the schedule putting unreasonable manpower and supervision constraints on it, i.e., it was working inefficiently. A bench trial was conducted and the Court found in favor of the subcontractor’s arguments. The Court found the general contractor had unrelated delays and that work activities were no longer methodical but, simply, piecemeal demands. The Court also rejected any inadequate manpower arguments finding the subcontract did not place any manpower requirements on the subcontractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Brenda Radmacher to Speak at Construction Super Conference 2024

November 05, 2024 — Brenda Radmacher - The Construction Seyt
Brenda Radmacher, partner in Seyfarth’s Construction group, will present and moderate panels at the 38thAnnual Construction Super Conference 2024 on December 9-11. The conference is recognized as the preeminent construction conference developed for mid to senior-level professionals working in legal and commercial construction markets. Panel – Looking Around Corners: Emerging Trends and Proactive Solutions Brenda will co-present a panel on innovative ways to engage experts in construction disputes, focusing on early expert involvement to aid in risk management, issue analysis, mitigation, and documentation for potential litigation. Panel – Top 10 Issues to Address in Your ADR Process for a Better Solution in Construction Disputes Read the full story...
Reprinted courtesy of Brenda Radmacher, Seyfarth
Ms. Radmacher may be contacted at bradmacher@seyfarth.com

Immigrants' Legal Status Eyed Over Roles in New York Fake Injury Lawsuits

January 07, 2025 — Richard Korman - Engineering News-Record
Edison Fernando Pesantez Ramon says that early on the morning of Sept. 29, 2021, while working on a building renovation project on 96th Street in Manhattan, he tripped and fell badly on a staircase. Read the full story...
Reprinted courtesy of Richard Korman, ENR
Mr. Korman may be contacted at kormanr@enr.com

Insurer Waives Objection to Appraiser's Partiality by Waiting Until Appraisal Issued

October 21, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The Eleventh Circuit affirmed the district court's denial of the insurer's objections on partiality grounds to the insured's appraiser. Biscayne Beach Club Condominium Association, Inc. v. Westchester Surpus Lines Ins. Co., 2024 U.S. App. LEXIS 19663 (11th Cir. Aug. 6. 2024). Storms damaged buildings at Biscayne Beach Club Condominium. Biscayne Beach filed claims with its insurer, Westchester. Unsatisfied with Westchester's payments, Biscayne Beach sued. Westchester then invoked the appraisal provision in the policy. The district court abated the action so the parties could pursue appraisal. Biscayne Beach appointed Lester Martin, its public adjuster, as its appraiser on a 10 percent contingency fee. Westchester objected because Martinez's retainer created a conflict of interest that would hinder his impartiality. Biscayne Beach then retained Blake Pyka as its appraiser. Westchester appointed its appraiser and and umpire was selected by the parties' two appraisers. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

COLUMBUS OHIO CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES