Columbus Ohio Construction Expert Witness Directory

Quick Note: Staying, Not Dismissing, Arbitrable Disputes Under Federal Arbitration Act

July 31, 2024 — David Adelstein - Florida Construction Legal Updates
As you hopefully know from posted articles, arbitration is a creature of contract. Stated differently, there must be a contractual basis to have a dispute resolved through binding arbitration. The Federal Arbitration Act (FAA) applies to transactions involving interstate commerce. Oftentimes, lawsuits are filed despite an arbitration provision in a contract because parties can, if they desire, waive their rights to have their dispute resolved through binding arbitration. In what should not be a shocker, the United States Supreme Court in Smith v. Spizzirri, 144 S.Ct. 1173, 1178 (2024), held that when a federal “district court finds that a lawsuit involves an arbitrable dispute, and a party requests a stay pending arbitration, section 3 of the FAA compels the court to stay the proceeding.” Dismissing the lawsuit should not be the option. Staying the lawsuit should. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Brenda Radmacher to Speak at Construction Super Conference 2024

November 05, 2024 — Brenda Radmacher - The Construction Seyt
Brenda Radmacher, partner in Seyfarth’s Construction group, will present and moderate panels at the 38thAnnual Construction Super Conference 2024 on December 9-11. The conference is recognized as the preeminent construction conference developed for mid to senior-level professionals working in legal and commercial construction markets. Panel – Looking Around Corners: Emerging Trends and Proactive Solutions Brenda will co-present a panel on innovative ways to engage experts in construction disputes, focusing on early expert involvement to aid in risk management, issue analysis, mitigation, and documentation for potential litigation. Panel – Top 10 Issues to Address in Your ADR Process for a Better Solution in Construction Disputes Read the full story...
Reprinted courtesy of Brenda Radmacher, Seyfarth
Ms. Radmacher may be contacted at bradmacher@seyfarth.com

There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense

October 01, 2024 — David Adelstein - Florida Construction Legal Updates
A federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!! In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:

The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.

Jackson Construction Co., supra, at 90.

Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

First Circuit Finds No Coverage For Subcontracted Faulty Work

December 17, 2024 — Eric Hermanson & Austin Moody - White and Williams LLP
After almost two years' deliberation, the First Circuit last week issued its long-awaited decision in Admiral Ins. Co. v. Tocci Bldg. Corp.[1]: affirming on other grounds, and leaving in place a district court decision that found subcontracted faulty work was not an "occurrence" and did not lead to covered “property damage” under Massachusetts law. The decision leaves Massachusetts among a number of states where general contractors should not expect coverage from their commercial general liability (CGL) insurers for damage falling within the contractor’s scope of work. Since the "scope of work" – where general contractors are involved – often encompasses an entire project, contractors who want coverage in Massachusetts should take care to make alternative arrangements: transferring risk to subcontractors through indemnity provisions and additional-insured endorsements, or relying on other policy forms where available. Reprinted courtesy of Eric Hermanson, White and Williams LLP and Austin Moody, White and Williams LLP Mr. Hermanson may be contacted at hermansone@whiteandwilliams.com Mr. Moody may be contacted at moodya@whiteandwilliams.com Read the full story...

More Musings on Why I Mediate

November 18, 2024 — Christopher G. Hill - Construction Law Musings
Whew! I’m back. And yes, I know it’s been a while (it has been a busy year, both personally and professionally). Hopefully, this will be the first of at least a few more consistent posts here at Construction Law Musings. Now, on with the post: Over the last few weeks, I’ve had a surge in mediation, both in my capacity as a mediator and as counsel for construction industry clients. These recent events have reaffirmed what I have always believed to be true, namely that no construction case is impossible to settle and avoid the cost and expense of litigation. I was also reminded of why I became a certified mediator and of the satisfaction that I get from helping individuals and construction companies find a business solution and closure. Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Three Kahana Feld Attorneys Selected to 2024 NY Metro Super Lawyers Lists

October 28, 2024 — Linda Carter - Kahana Feld
Kahana Feld is pleased to announce that Tim Capowski was selected to the 2024 NY Metro Super Lawyers list, and Christopher Theobalt and Sofya Uvaydov were selected to the 2024 NY Metro Rising Stars list. All three attorneys were recognized in the Appellate practice area. Tim Capowski is a partner at Kahana Feld and chair of the firm’s National Appellate Litigation & Consulting Group. He has spent the better part of three decades at the forefront of the insurance defense bar. Tim has litigated hundreds of appeals and thousands of motions in state and federal and appellate courts throughout New York and around the country. He handles a variety of complex litigation including catastrophic property and casualty claims, construction defect, professional liability, labor and employment law, mass torts, insurance coverage, and more. Read the full story...
Reprinted courtesy of Linda Carter, Kahana Feld
Ms. Carter may be contacted at lcarter@kahanafeld.com

Third Circuit Vacates Judgment for Insurer on Alleged Construction Defect Claim

December 31, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The Third Circuit vacated and remanded to the district court the judgment in favor of the insurer on a construction defect claim. Odedeyi v. AmTrust Financial Services Inc., 2024 U.S. App. LEXIS 24729 (3d Cir. Oct. 1, 2024). Mr. Odedeyi hired a contractor, who was insured by Security National, to perform work on his property. After the property was damaged during the renovations, Odedeyi filed suit against the contractor. Odedeyi was awarded a default judgment against the contractor. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Supreme Court Upholds Prevailing Wage Statute

August 19, 2024 — Ahlers Cressman & Sleight PLLC
Historically, the prevailing wage was calculated by averaging the wages within a certain industry and county. However, in 2018 the Washington Legislature amended the statute so that the prevailing wage would be assessed based on the highest wage set by collective bargaining agreements in the county. The amendment (RCW 39.12.015(3)) reads as follows: (3)(a)…the industrial statistician shall establish the prevailing rate of wage by adopting the hourly wage, usual benefits, and overtime paid for the geographic jurisdiction established in collective bargaining agreements… (b) For trades and occupations in which there are no collective bargaining agreements in the county, the industrial statistician shall establish the prevailing rate of wage by…conducting wage and hour surveys. So, for example, if union engineers bargain for a wage, that is the wage all engineers in the county must be paid on public projects. The legislature passed this law for the sake of efficiency because it took significant resources for the Industrial Statistician to compute the prevailing wage for every trade and every county, but the law has significant knock-on effects. Read the full story...
Reprinted courtesy of Ahlers Cressman & Sleight PLLC

COLUMBUS OHIO CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES