FAIRFIELD CONNECTICUT CONSTRUCTION EXPERT WITNESS
DIRECTORY AND CAPABILITIES

Supreme Court Opens Door for Challenges to Older Federal Regulations

August 05, 2024 — Jane C. Luxton - Lewis Brisbois
Washington, D.C. (July 1, 2024) – On July 1, 2024, the U.S. Supreme Court issued another end-of-term major decision limiting the scope of federal agency actions in Corner Post, Inc. v. Board of Governors of the Federal Reserve System. Adding to the tectonic shift in the regulatory landscape created by the Court’s June 27 and 28 rulings constraining the role of administrative law judges and overturning longstanding “Chevron deference” by courts to federal agency expertise, the decision in Corner Post establishes a newly expanded time frame for affected entities to challenge final agency action. Instead of confirming that final agency action is subject to a default six-year statute of limitations, the Court held that under the Administrative Procedure Act (APA), the time limit for appeal begins to run when a plaintiff is injured by the agency's action, not when the action becomes final. This decision has important implications for businesses and others affected by federal regulations. The case arose when Corner Post, a truck stop and convenience store in North Dakota that opened in 2018, challenged a 2011 Federal Reserve Board regulation (Regulation II) that set maximum interchange fees for debit card transactions. Corner Post filed suit in 2021, arguing that Regulation II allowed higher fees than permitted by statute. The lower courts dismissed the suit as time-barred under 28 U.S.C. § 2401(a), which effectively requires APA claims to be filed "within six years after the right of action first accrues." Read the full story...
Reprinted courtesy of Jane C. Luxton, Lewis Brisbois
Ms. Luxton may be contacted at Jane.Luxton@lewisbrisbois.com

---

Boston Team Secures Summary Judgment Dismissal on Client’s Behalf in Serious Personal Injury Case

October 21, 2024 — Lewis Brisbois Newsroom
Boston, Mass. (October 14, 2024) - Boston Managing Partner Kenneth B. Walton and Partner Matthew M. O' Leary recently secured summary judgment on behalf of a civil engineering firm in a serious personal injury matter arising from a trip-and-fall incident in a mall parking lot. The client was retained to provide site civil engineering design for the parking lot of a local mall. The design included multiple bioretention areas known as rain gardens. In November of 2019, a woman tripped and fell while attempting to cross a rain garden to reach her car. She suffered significant bodily injuries, including a fracture of the cervical spine that resulted in partial paralysis. The woman and her husband sued the mall's owner for negligence and loss of consortium in June 2021. The owner, in turn, impleaded Lewis Brisbois' client and the lot's builder, asserting third-party claims for contribution, contractual and common law indemnity, and breach of contract. In addition, the builder cross-claimed against Lewis Brisbois' client for contribution and common law indemnity. Read the full story...
Reprinted courtesy of Lewis Brisbois

---

What Every Project Participant Needs to Know About Delay Claims

August 05, 2024 — Andrew G. Vicknair - The Dispute Resolver
A “delay” on a construction project is defined as the stretching out of the time for completion of certain key milestone scopes of work which can impact the completion date of an entire project, due to some circumstances or events that were not reasonably anticipated when the project began. 2 Construction Law ¶ 6.01 (Matthew Bender, 2024). While delays can be caused by any number of events, the most common are defective plans and specifications; design changes; severe weather and other, similar unforeseeable events; unforeseen or differing site conditions; unavailability of materials or labor; labor inefficiencies or stoppages; contractor negligence; and owner influences, including construction changes or outright interference by the owner or its agents. If the project schedule is not recovered following a delay, then the project schedule will likely be extended, resulting in an increase in the contractor’s costs of performance. A contractor that has experienced a delay on a project can take certain actions to pursue recovery of any damages the contractor may have incurred. However, to do so it is important to understand the different types of delays and the methods for establishing the delays. I. Types of Delays Delays may be categorized as (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. A critical delay is a delay that affects the project completion date and delays the entire project. In essence, a critical delay is one that will extend the critical path of a project. A non-critical delay is a delay that has no effect on the project’s critical path. Courts have recognized that delays to work not on the critical path will generally not delay the completion of a project. G.M. Shupe, Inc. v U.S., 5 Cl. Ct. 662, 728 (1984). Such a non-critical delay may affect the completion of certain activities, but does not affect the completion date of the entire project. In order for a delay to provide the basis for a claim for additional time or money, the delay must impact critical path activities on the project schedule. Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

---

Policy's One Year Suit Limitation Does Not Apply to Challenging the Insurer's Claims Handling

October 07, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The California Supreme Court held that the policy's suit limitation of one year, consistent with the statute requiring suit be file within twelve months after a loss, did not apply to claims alleging violation of the state's unfair competition law (UCL). Rosenberg-Wohl v. State Farm Fire and Cas. Co., 2024 Cal. LEXIS 3806 (Cal. July 18, 2024). Plaintiff held a homeowners policy issued by State Farm that provided coverage for all risks except those specifically excluded under the policy. The suit limitation provision provided, "Suit Against Us. No action shall be brought unless there has been compliance with the policy provision.The action must be started within one year after the date of loss or damage." On two occasions in late 2018 or early 2019, plaintiff's neighbor stumble and fell as she descended a staircase at plaintiff's residence. Plaintiff discovered that the pitch of the stairs had changed, and replacement of the stairs was required to fix the issue. She contacted State Farm on or around April 23, 2019. On August 9, 2019, plaintiff submitted a claim to State Farm, seeking reimbursement for what she paid to repair the staircase. State Farm denied the claim, advising there was no coverage and identifying several exclusions as potentially applicable. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Why Should Businesses Seek Legal Help Early On?

December 03, 2024 — Scott L. Baker - Los Angeles Litigation Blog
Most business owners are natural problem solvers. They assess the issue that lies before them and develop a strategy to overcome it. It’s a critical mindset to have, but do all business owners have the skillset to solve every issue? While it is understandable that business owners may want to attempt to resolve issues on their own, it is invariably beneficial to obtain guidance for legal issues earlier rather than later. 3 Reasons to Consult an Attorney Sooner than Later Many people might consider working with an attorney to be a last resort. Typically, this is not the case; rather, getting knowledgeable legal counsel sooner than later can help business owners because:

1. It’s Cheaper: Early legal intervention can often prevent disputes from leading to litigation, which can be expensive. Working with an attorney to resolve a conflict before it escalates into a larger issue is often a good business decision and wise investment.

Read the full story...
Reprinted courtesy of Scott L. Baker, Baker & Associates
Mr. Baker may be contacted at slb@bakerslaw.com

---

EPA Looks to Reduce Embodied Carbon in Materials With $160M in Grants

August 19, 2024 — James Leggate - Engineering News-Record
The U.S. Environmental Protection Agency estimates that construction materials used for buildings and built infrastructure account for more than 15% of global greenhouse gas emissions. The agency now hopes to boost adoption of materials with lower embodied emissions by offering $160 million in grants to better track and ultimately reduce climate pollution associated with those materials. Reprinted courtesy of James Leggate, Engineering News-Record Mr. Leggate may be contacted at leggatej@enr.com Read the full story...

---

David Uchida Joins Kahana Feld’s Los Angeles Office as Partner

December 31, 2024 — Linda Carter - Kahana Feld
Kahana Feld is pleased to announce that David M. Uchida recently joined the firm as a partner in the firm’s Los Angeles Office. He is a member of the firm’s General Liability group. A client-focused and seasoned litigator, David has defended product manufacturers and suppliers in complex toxic tort and environmental litigation. David also has extensive experience defending clients in alleged asbestos, benzene, and silica exposure claims. Read the full story...
Reprinted courtesy of Linda Carter, Kahana Feld
Ms. Carter may be contacted at lcarter@kahanafeld.com

---

NCDOT Aims to Reopen Helene-damaged Interstate 40 by New Year's Day

December 10, 2024 — Derek Lacey - Engineering News-Record
Interstate 40, closed in late September when flooding from Hurricane Helene caused multiple landslides and washouts in the Pigeon River Gorge between North Carolina and Tennessee, is expected to partially reopen on New Year’s Day 2025, more than three months after the storm. Long-term reconstruction plans are still in early development. Read the full story...
Reprinted courtesy of Derek Lacey, ENR
Mr. Lacey may be contacted at laceyd@enr.com

---