SEATTLE WASHINGTON CONSTRUCTION EXPERT WITNESS
DIRECTORY AND CAPABILITIES

Takeaways From Schedule-Based Dispute Between General Contractor and Subcontractor

September 09, 2024 — David Adelstein - Florida Construction Legal Updates
A recent opinion out of the Southern District of Florida, Berkley Insurance Co. v. Suffolk Construction Co., Case 1:19-cv-23059-KMW (S.D.Fla. July 22, 2024), provides valuable takeaways on schedule-based disputes between a general contractor and subcontractor on a high-rise project. In a nutshell, the general contractor’s original project schedule was abandoned due to project delays and the project wasn’t being built by any updated project schedule. The subcontractor claimed the general contractor was mismanaging the schedule putting unreasonable manpower and supervision constraints on it, i.e., it was working inefficiently. A bench trial was conducted and the Court found in favor of the subcontractor’s arguments. The Court found the general contractor had unrelated delays and that work activities were no longer methodical but, simply, piecemeal demands. The Court also rejected any inadequate manpower arguments finding the subcontract did not place any manpower requirements on the subcontractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Why Being Climate ‘Positive’ Is the Buzzy New Goal of Green Building

December 10, 2024 — Olivia Rudgard - Bloomberg
The three buildings, dotted around Norway, couldn’t look more different: a soaring timber-and-concrete obelisk in Porsgrunn; a squat, two-story Montessori school on the edge of a forest in Drøbak; and a concrete and glass wedge-shaped office in Trondheim, just a few hundred miles from the edge of the Arctic Circle. But they share a distinctive feature. Each has a roof perfectly tilted to squeeze out every possible drop of solar energy. They are called Powerhouses, and the initiative behind them claims they are all “energy positive”: The upfront energy “cost” of each building, and that of later demolition and disposal, is expected to be made back over the building’s lifetime. Powerhouses sometimes draw from the grid, especially in winter, but in the long Nordic summer days they give back many times over, overspilling excess solar energy into surrounding homes and businesses. Read the full story...
Reprinted courtesy of Olivia Rudgard, Bloomberg

---

Courthouse Reporter Series: Louisiana Supreme Court Holds Architect Has No Duty to Safeguard Third Parties Against Injury, Regardless of Knowledge of Dangerous Conditions on the Project

July 31, 2024 — Stu Richeson - The Dispute Resolver
In Bonilla v. Verges Rome Architects, 2023-00928 (La. 3/22/24); 382 So.3d 62, the Louisiana Supreme Court held because the terms of the agreement between the architect and the public owner did not give the architect responsibility for the means and methods of construction or for safety on the project, the architect did not have a duty to safeguard third parties against injury, regardless of whether the architect may have had knowledge of dangerous conditions on the project. In Bonilla, the City of New Orleans entered into a contract for the renovation of a building owned by the city. The city also entered into an agreement with Verges Rome Architects (“VRA”) to serve as the project architect. The general contractor on the project subcontracted the demolition work to Meza Services, Inc. (“Meza”). An employee of Meza was injured while attempting to demolish a “vault” on the project. The vault was a ten-foot by ten-foot cinderblock room with a nine-foot-high concrete slab ceiling located on the second floor of the building. The walls of the vault had been partially demolished when one of the employees of Meza was directed by his supervisor to stand on the ceiling of the vault with a jackhammer to continue the demolition. Shortly after beginning the task, the vault structure collapsed and caused the employee to suffer significant injury. Read the full story...
Reprinted courtesy of Stu Richeson, Phelps
Mr. Richeson may be contacted at stuart.richeson@phelps.com

---

What You Need to Know to Protect the Project Against Defect Claims

October 28, 2024 — Scott L. Baker - Los Angeles Litigation Blog
If a property owner claims there is a construction defect, that not only brings the project’s integrity into question but also your business’s reputation. So, how can you take steps to prevent these claims from causing such damage? Here are three things to know before beginning a project to effectively protect it and manage construction defect claims. 1. Documentation is key California and Los Angeles County require certain permits and documents in order for a construction project to move forward. Los Angeles County will also conduct plan checks to ensure everything is up to code. Detailed documentation will be important while making your plans. However, keeping notes throughout every step of the project will also be essential. Documenting all aspects of the project helps you:

• Stay updated and aware of the project’s progress
• Proactively catch and handle issues that could result in disputes
• Create a record of evidence that can help manage defect claims

Read the full story...
Reprinted courtesy of Scott L. Baker, Baker & Associates
Mr. Baker may be contacted at slb@bakerslaw.com

---

Best Lawyers® Recognizes 49 White and Williams Attorneys

September 16, 2024 — White and Williams LLP
Thirty-eight White and Williams lawyers were recognized in Best Lawyers in America® 2025. Inclusion in Best Lawyers® is based entirely on peer-review. The methodology is designed to capture, as accurately as possible, the consensus opinion of leading lawyers about the professional abilities of their colleagues within the same geographical area and legal practice area. Best Lawyers® employs a sophisticated, conscientious, rational, and transparent survey process designed to elicit meaningful and substantive evaluations of quality legal services. In addition, eleven lawyers were recognized as Best Lawyers: Ones to Watch® in America. This recognition is given to attorneys who are earlier in their careers for outstanding professional excellence in private practice in the United States. The firm is also pleased to announce Best Lawyers® has recognized three attorneys as "Lawyer of the Year” including: Chuck Eppolito, Litigation - Health Care, Philadelphia, who focuses his practice on medical malpractice defense as well as other insurance-related defense; William D. Kennedy, Litigation – Insurance, Philadelphia, who focuses his practice on complex claims of injury and damage arising in both the professional and general liability contexts; and, Michael O. Kassak, Litigation – Insurance, Cherry Hill, who focuses his practice on large complex commercial matters including insurance coverage and healthcare disputes. Read the full story...
Reprinted courtesy of White and Williams LLP

---

Real Estate & Construction News Roundup (9/4/24) – DOJ Sues RealPage, Housing Sales Increase and U.S. Can’t Build Homes Fast Enough

October 07, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, environmental regulations tighten for commercial properties, Wells Fargo sells most of its commercial mortgage services business, first-time home buyers struggle with housing affordability, and more!

• The U.S. Department of Justice announced that it is suing the real estate company RealPage, saying it engaged in a price-fixing scheme to drive up rents. (Jennifer Ludden, NPR)
• As environmental regulations for commercial buildings and properties tighten across the U.S., green leases and technologies offer owners and operators opportunities to reduce their portfolios’ carbon footprints, generate cost savings and further align with ESG goals. (Nish Amarnath, Construction Dive)
• Wells Fargo & Co. agreed to sell most of its commercial mortgage servicing business to Trimont LLC, ceding the title of biggest US commercial and multifamily mortgage servicer to the Atlanta-based firm. (Hannah Levitt and Scott Carpenter, Yahoo)

Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

---

Mitigating Mold Exposure in Manufacturing and Multifamily Buildings

July 31, 2024 — Laura Champagne - Construction Executive
As hurricanes season and summer storms approach, more apartment complexes, commercial and industrial properties, and public buildings are at risk of leaking and flooding. Water-saturated structures are prime breeding grounds for mold, but there are ways to prevent, detect and remove it before it becomes a serious and costly issue—for buildings and building residents alike. Being proactive limits an owner’s exposure to the liability of debilitating health effects and structural safety concerns. Mold requires three things to grow: water, food and humidity. Water will stealthily penetrate small porous surfaces of any building material, such as drywall, plaster, wood, concrete or even fabrics. These materials serve as a food source to quickly produce more fungus. Common sources of undetected water flow include foundation problems, poorly installed windows, roof malfunctions, gutter clogs, storm damage, leaky pipes, improper drainage, HVAC issues, faulty appliances, bathroom vent issues and wet building materials. Mold loves humidity and thrives in dark, warm environments, such as attics, basements, lofts, building corners and bathrooms. Reprinted courtesy of Laura Champagne, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

---

Untangling Unique Legal Issues in Modern Modular Construction

September 09, 2024 — Chad Theriot & Brad Sands - Construction Executive
Modular construction has grown significantly over the last few years and shows no signs of slowing down. This construction method is a departure from traditional approaches where all construction activity occurs onsite. Modular construction involves building standardized project components—usually in an offsite, controlled environment—which are then transported and assembled at the project site. Offsite construction generally allows for better quality control and economic efficiency, as it can utilize an assembly-line process. Modular fabrication can also centralize skilled labor in regions with lower labor costs. Establishing each party's expectations upfront is always important, but even more so in modular construction since much of the construction activity is performed away from the ultimate project site. This requires extensive coordination among designers, fabricators, installers and owners to ensure construction, testing and quality progresses accordingly. Every field change and design clash could have an exponential impact on the modular fabrication efficiencies given the assembly-line approach and remote nature of modular work. Reprinted courtesy of Chad Theriot & Brad Sands, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

---