SEATTLE WASHINGTON CONSTRUCTION EXPERT WITNESS
DIRECTORY AND CAPABILITIES

What Every Project Participant Needs to Know About Delay Claims

August 05, 2024 — Andrew G. Vicknair - The Dispute Resolver
A “delay” on a construction project is defined as the stretching out of the time for completion of certain key milestone scopes of work which can impact the completion date of an entire project, due to some circumstances or events that were not reasonably anticipated when the project began. 2 Construction Law ¶ 6.01 (Matthew Bender, 2024). While delays can be caused by any number of events, the most common are defective plans and specifications; design changes; severe weather and other, similar unforeseeable events; unforeseen or differing site conditions; unavailability of materials or labor; labor inefficiencies or stoppages; contractor negligence; and owner influences, including construction changes or outright interference by the owner or its agents. If the project schedule is not recovered following a delay, then the project schedule will likely be extended, resulting in an increase in the contractor’s costs of performance. A contractor that has experienced a delay on a project can take certain actions to pursue recovery of any damages the contractor may have incurred. However, to do so it is important to understand the different types of delays and the methods for establishing the delays. I. Types of Delays Delays may be categorized as (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. A critical delay is a delay that affects the project completion date and delays the entire project. In essence, a critical delay is one that will extend the critical path of a project. A non-critical delay is a delay that has no effect on the project’s critical path. Courts have recognized that delays to work not on the critical path will generally not delay the completion of a project. G.M. Shupe, Inc. v U.S., 5 Cl. Ct. 662, 728 (1984). Such a non-critical delay may affect the completion of certain activities, but does not affect the completion date of the entire project. In order for a delay to provide the basis for a claim for additional time or money, the delay must impact critical path activities on the project schedule. Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

---

Surprising Dismissal of False Claims Act Case Based on Appointments Clause - What Does It Mean?

October 15, 2024 — Steven H. Lee - Lewis Brisbois Newsroom
Atlanta, Ga. (October 1, 2024) - In a surprising turn of events, the U.S. District Court for the Middle District of Florida recently dismissed a False Claims Act (FCA) lawsuit brought by relator Clarissa Zafirov against Florida Medical Associates, LLC, and other defendants. U.S. District Judge Kathryn Kimball Mizelle ruled that the FCA’s qui tam provisions, which allow private individuals to bring lawsuits on behalf of the government, violate the Constitution’s Appointments Clause. This decision follows another unexpected ruling by U.S. District Judge Aileen Cannon in the Southern District of Florida, where the court similarly dismissed an indictment against former President Donald Trump based on the same constitutional clause. At the heart of these rulings is the argument that FCA relators - who decide whom to sue, which legal theories to pursue, and how to proceed - exercise significant executive authority. Because they are not appointed by the President, a department head, or a court, the judges concluded that these relators hold their positions unconstitutionally. As a result, Judge Mizelle dismissed the case entirely. Read the full story...
Reprinted courtesy of Steven H. Lee, Lewis Brisbois
Mr. Lee may be contacted at Steven.Lee@lewisbrisbois.com

---

Finding Insurer's Declaratory Relief Action Raises Unsettled Questions of State Law, Case is Dismissed

November 05, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The federal district court for the District of Hawaii dismissed the insurer's action for declaratory relief because it raised issues that were unsettled by Hawaii courts. Association of Apartment Owners of Lahaina Residential Condominium, et al., No. 1-24-cv-00075-JAO-BMK, Order Granting AOAO's Motion to Dismiss (D. Haw. Aug. 29, 2024). The case addressed whether a property damage exclusion barred coverage over an owner's claim that a condominium association and its property manager failed to obtain adequate insurance before the condominium's property was damaged by the Maui wildfire in August 2023. Great American filed suit seeking a declaration that it had no duty to defend or indemnify the Association and the property manage, Quam Properties Hawaiiana, Inc., in connection with a demand for mediation submitted to the Association and Quam on behalf of one of the owners. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

NCCER Celebrates Construction Education Programs and Products in 2024

January 07, 2025 — The National Center for Construction Education and Research
ALACHUA, Fla., Dec. 30, 2024 (GLOBE NEWSWIRE) -- The National Center for Construction Education and Research (NCCER) released several new or updated educational products in 2024, serving its ongoing mission to provide workforce development solutions for the construction industry and impacting 330,000 people. NCCER's newest craft training products include a new certification program, multiple curricula updates, new Spanish curriculum translations, and NCCERconnect digital courses and resources. One of the highlights of the year was the launch of the brand-new Construction Foreman Certification Program. Helping to fill a significant gap in formal training for frontline supervisors, the program covers critical areas of field leadership such as people management, communication, quality, safety and productivity. The Construction Foreman Certification Program is the latest offering in NCCER's Construction Leadership Series (CLS), which provides turnkey, self-paced online certification solutions for leadership development. The first title in the CLS, the Construction Superintendent Certification Program, debuted in 2023. About NCCER – The National Center for Construction Education and Research (NCCER) is an independent 501(c)(3) nonprofit education foundation and the leading provider of construction education for industry and career and technical education programs. With flexible workforce development and learning solutions, NCCER's programs provide consistency and quality to ensure craft professionals and learners receive industry-recognized credentials and certifications. To learn more, visit www.nccer.org.

---

Traub Lieberman Attorneys Recognized as 2024 New York – Metro Super Lawyers®

November 11, 2024 — Traub Lieberman
Traub Lieberman is pleased to announce that seven Partners from the Hawthorne, NY office have been selected to the 2024 New York - Metro Super Lawyers list. 2024 New York – Metro Super Lawyers

• Copernicus Gaza – Insurance Coverage
• Jonathan Harwood – Professional Liability
• Lisa Rolle – Construction Litigation
• Hillary Raimondi – Employment Litigation
• Christopher Russo – Professional Liability
• Lisa Shrewsberry – Professional Liability
• Stephen Straus – Insurance Coverage

Lisa Shrewsberry was also selected to the Top 25: 2024 Westchester County Super Lawyers® list. Read the full story...
Reprinted courtesy of Traub Lieberman

---

In Kansas City, a First-Ever Stadium Designed for Women’s Sports Takes the Field

December 17, 2024 — Mark Byrnes - Bloomberg
The Kansas City Current won its first-ever at-home playoff match on Nov. 9, a breakthrough for the team playing its fourth season in the National Women’s Soccer League. Although the Current’s postseason push ended a week later in a semifinals loss, women’s soccer nevertheless returns to Kansas City, Missouri, for the national championship on Nov. 23. The title match will be a landmark for all of women’s sports: CPKC Stadium, the new home for the Current and host of the NWSL championship game, is the first purpose-built women’s professional sports stadium in the world. Designed by Generator Studio, a women-led firm based in Kansas City, CPKC Stadium gives the young franchise a permanent base while providing inspiration for other women’s clubs looking for equal footing in an increasingly competitive and expensive era of stadium development. The Current played their first match at CPKC Stadium to a sellout crowd this spring, and attendance hasn’t dropped since. Read the full story...
Reprinted courtesy of Mark Byrnes, Bloomberg

---

‘The Ground Just Gave Out’: How a Storm’s Fury Ravaged Asheville

October 07, 2024 — Michael Smith, Devon Pendleton, Claire Ballentine & Michael Sasso - Bloomberg
Eric Becker was at his vacation home in western North Carolina, in a community bordering the Pisgah National Forest and Blue Ridge Parkway, when the rain began to pour. Becker, co-founder of the private wealth management firm Cresset, lives in Florida for most of the year. He had lived through a hurricane — but nothing like what he saw during Helene. “Mud was liquefying around tree bases. You could see the root systems,” said Becker, who first began visiting the Asheville area 20 years ago and was smitten by its natural scenery, excellent food and lively arts and music scene. “The ground just gave out.” Becker is part of a wave of affluent homebuyers who have flocked to the southern Appalachian region. Transplants from wealth managers and retirees to artists and young outdoors enthusiasts have helped create a real estate goldrush in cities including Asheville, where home prices have climbed 69% in the past five years. Reprinted courtesy of Michael Smith, Bloomberg, Devon Pendleton, Bloomberg, Claire Ballentine, Bloomberg and Michael Sasso, Bloomberg Read the full story...

---

Is the Construction Industry Actually a Technology Hotbed?

August 19, 2024 — Andrew Silver - Construction Executive
Technology has always been a driving force behind progress, and the construction industry is no exception. Over the years, technological advancements have revolutionized the way companies design, plan and build structures, leading to increased efficiency, safety and sustainability. From virtual-reality simulations to drones and 3D printing, technology has transformed every aspect of the construction process. However, the construction trades still lag behind other sectors in adoption of digital technologies. With a lack of skilled labor continuing to be an impediment to growth and profitability in the construction industry, technological developments could have significant implications for successful adopters. Already, the industry is seeing a huge difference in valuation between traditional engineering and construction firms and construction software companies. As labor shortages continue to hinder growth in the industry, consolidation is likely, as is the probability that companies with the greatest tech capabilities will be the most highly valued. There are several areas of technology that are of the greatest interest in the current marketplace. BIM Building information modeling with computer-aided design software now allows architects and engineers to create detailed and accurate 3D models of buildings and infrastructure projects, integrating data about every aspect of the building, from materials and costs to energy efficiency and maintenance schedules. These models not only help in visualizing the final product; they also enable better communication and collaboration among project stakeholders. Reprinted courtesy of Andrew Silver, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

---