COLUMBUS OHIO CONSTRUCTION EXPERT WITNESS
DIRECTORY AND CAPABILITIES

Recovering Time and Costs from Hurricane Helene: Force Majeure Solutions for Contractors

November 18, 2024 — Matthew DeVries - Best Practices Construction Law
When Hurricane Helene struck North Carolina, it caused severe disruptions to construction projects across the state. Baxter International’s North Cove facility in Marion, N.C., was completely shut down after floodwaters damaged the site and bridges leading to it. Elsewhere, landslides and floods wiped out large sections of Interstate 40, making transportation of materials and equipment nearly impossible. Many contractors in western North Carolina found their projects halted, and their schedules thrown off by this force majeure event. In situations like these, contractors and subcontractor need a plan to mitigate the impact of such natural disasters on their projects. Here are five practical tips to help you secure time extensions and/or compensation for delays: 1. Include a Robust Force Majeure Clause in Your Contract When disaster strikes, your contract is your first line of defense. A well-drafted force majeure clause can make the difference between bearing the costs yourself and getting an extension or compensation. The clause should clearly list specific events such as hurricanes, floods, and road closures as qualifying force majeure events. Read the full story...
Reprinted courtesy of Matthew DeVries, Buchalter
Mr. DeVries may be contacted at mdevries@buchalter.com

---

Bally's Secures Funding for $1.7B Chicago Casino and Hotel Project

August 12, 2024 — Annemarie Mannion - Engineering News-Record
Plans for a $1.7-billion casino and adjacent 34-story hotel are advancing in Chicago as the gaming operator reports it has secured $940 million to complete funding for the project and has set demolition for a printing press building now occupying the site for this summer. Reprinted courtesy of Annemarie Mannion, Engineering News-Record Ms. Mannion may be contacted at manniona@enr.com Read the full story...

---

Congratulations to Partner Alex Giannetto for Being Named to San Diego Business Journal’s Top 100 Leaders in Law List

December 03, 2024 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Congratulations to Partner Alexander Giannetto for being selected as a “2024 Leaders of Influence in Law” by the San Diego Business Journal! To read and download the SDBJ publication, please click here. Alex Giannetto is a managing partner with Bremer, Whyte, Brown & O’Meara LLP’s San Diego office. He has extensive experience in all aspects of civil litigation handling liability matters including slip and falls, catastrophic injuries, wrongful death, traumatic brain injuries, landslides, and construction claims. He has obtained favorable trial results defending clients on personal injury and premises matters in San Diego and Los Angeles. He also has appellate experience. He is an AV-rated attorney by Martindale-Hubbell who has been voted Best of the Bar in San Diego as well as a Top Lawyer in San Diego. Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

---

Construction Defect Claim Survives Insurer's Summary Judgment Motion Due to Lack of Evidence

December 23, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The court denied the insurer's motion for summary judgment on a construction defect claim due to lack of evidence. Statesboro Erectors, Inc. v. Owners Ins. Co., 2024 U.S. Dist. LEXIS 176555 (N.D. Ga. Sept. 30, 2024). Griffco was the general contractor for a construction project. King Steel was hired as the "steel fabricator." King Steel subcontracted with Statesboro Erectors to complete certain construction work at the site. Statesboro agreed to the complete, proper and safe erection of the structural steel. A steel collapse occurred at the construction site. According to King Steel, the collapse "appeared to have occurred due to lack of temporary cables or bracing for steel columns." Because of the collapse, King Steel was required to supply additional materials to replace the structural damage caused by the collapse. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Real Estate & Construction News Roundup (10/23/24) – Construction Backlog Rebounds, Real Estate Sustainability Grows, and Split Incentive Gap Remains Building Decarbonizing Barrier

November 18, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, construction output decreased, office utilization unchanged, September apartment starts fell 15% from a year ago as developers pulled permits, and more!

• Developers pulled permits for a seasonally adjusted rate of 398,000 apartments in buildings with five units or more, a 17.4% YOY drop and a 10.8% decrease compared to August 2024. (Leslie Shaver, Multifamily Dive)
• Construction input prices decreased 0.9% in September due to dips in two of three energy subcategories, reflecting the trend of overall material price stabilization over the past 12 months. (Sebastian Obando, Construction Dive)
• Thanks in part to the Federal Reserve’s lowering of the interest rate, construction backlog rebounded in September after slumping at the end of the summer. (Joe Bousquin, Construction Dive)

Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

---

WSHB Secures Victory in Construction Defect Case: Contractor Wins Bench Trial

October 01, 2024 — Wood Smith Henning & Berman
Wood Smith Henning & Berman is pleased to announce a significant victory in a bench trial led by trial attorney Thomas Fama. The case, which had been pending for nearly five years due to pandemic-related delays and unreasonable demands by the plaintiff, concluded with a resounding judgment in favor of the defendant. "The result of this trial is a testament to our team's unwavering tenacity and strategic focus throughout the entire process," stated WSHB partner Tom Fama, lead counsel in the case. "We kept our eye on the proverbial ball and diligently worked to expose the lack of evidence supporting the plaintiff's claims." The matter involved allegations of defective installation of a solar energy system, which the plaintiff claimed leaked during inclement weather. Fama and his team successfully demonstrated that the plaintiff's claims lacked substance, highlighting numerous pre-existing conditions on the roof that could have been responsible for the problem. Read the full story...
Reprinted courtesy of Wood Smith Henning & Berman

---

Summary Judgment for Insurer on Construction Defect Claim Reversed

January 07, 2025 — Tred R. Eyerly - Insurance Law Hawaii
The Fifth Circuit reversed the district court's granting of summary judgment to the insurer on a construction defect claim asserted against the insured. TIG Ins. Co. v. Woodsboro Farmers Cooperative, 2024 U.S. App. LEXIS 24003 (5th Cir. Sept. 20, 2024). In March 2013, Woodsboro Farmers Cooperative contracted with E.F. Erwin, Inc. to construct two Brock 105' diameter grain silos. Erwin hired subcontract AJ Constructors, Inc. (AJC) to construct the silos. Erwin was responsible for supervising the work. Brock silos were kits shipped by the manufacturer and then assembled according to the manufacturer's manuals and specifications. The silos are constructed section by section. AJC began erecting the silos in May 2013 and completed its work in June or early July. Erwin occasionally inspected the work and found the silos were structurally sound and not defective. AJC left the job site after completing the assembly. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Athens, Ohio, Sues to Recover Nearly $722,000 After Cyber Attack

January 21, 2025 — Jeff Yoders - Engineering News-Record
In November, Athens, Ohio, officials sent nearly $722,000 to a bank account they believed was set up by its contractor, Pepper Construction, to receive payment for its work on a fire station headquarters. The request was actually a sophisticated cyber attack that took advantage of a construction payment system that often does not allow clients processing invoices to directly know those behind the email addresses making the requests. Read the full story...
Reprinted courtesy of Jeff Yoders, ENR
Mr. Yoders may be contacted at yodersj@enr.com

---