Columbus Ohio Construction Expert Witness Directory

Toolbox Talk Series Recap - Undocumented Change Work

October 15, 2024 — Douglas J. Mackin - The Dispute Resolver
In the August 29, 2024 edition of Division 1's Toolbox Talk Series, Don Rea presented on the causes of undocumented change order work and what actions parties to a construction project can take to protect themselves, which compliments and reinforces some of the key points from the May 30, 2024 Toolbox Talk on maximizing profits while experiencing changes during project performance. Article 7 of AIA A201 General Conditions covers (i) change orders, (ii) constructive change directives, and (iii) “minor changes.” Work that falls outside the scope of the construction contract will often fit into one of these three categories. Rea’s presentation focused on the fact that, regardless of which category applies, proper documentation of the change work is vital. Read the full story...
Reprinted courtesy of Douglas J. Mackin, Cozen O’Connor
Mr. Mackin may be contacted at dmackin@cozen.com

Takeaways From Schedule-Based Dispute Between General Contractor and Subcontractor

September 09, 2024 — David Adelstein - Florida Construction Legal Updates
A recent opinion out of the Southern District of Florida, Berkley Insurance Co. v. Suffolk Construction Co., Case 1:19-cv-23059-KMW (S.D.Fla. July 22, 2024), provides valuable takeaways on schedule-based disputes between a general contractor and subcontractor on a high-rise project. In a nutshell, the general contractor’s original project schedule was abandoned due to project delays and the project wasn’t being built by any updated project schedule. The subcontractor claimed the general contractor was mismanaging the schedule putting unreasonable manpower and supervision constraints on it, i.e., it was working inefficiently. A bench trial was conducted and the Court found in favor of the subcontractor’s arguments. The Court found the general contractor had unrelated delays and that work activities were no longer methodical but, simply, piecemeal demands. The Court also rejected any inadequate manpower arguments finding the subcontract did not place any manpower requirements on the subcontractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

New York Appellate Team Obtains Affirmance of Dismissal of Would-Be Labor Law Action Against Municipal Entities

August 12, 2024 — Lewis Brisbois Newsroom
New York, N.Y. (July 11, 2024) - In Charlot v. City of New York, ___ A.D.3d ___, 2024 NY Slip Op 03161 (2d Dep’t 2024), New York Associate Dean Pillarella, a member of the Appellate Practice, recently obtained an affirmance of the lower court’s dismissal of the plaintiff’s action against the City of New York (“the City”) for failure to timely serve a notice of claim. New York Partner Meghan Cavalieri, a member of the Construction Practice, and her team authored and argued the initial motion to dismiss. The plaintiff alleged to have sustained injuries as a result of a construction-site accident on December 8, 2020, on City-owned property in the course of the construction of a school by the New York City School Construction Authority. N.Y. General Municipal Law (“GML”) § 50-e(1)(a), requires service of a notice of claim within 90 days after the claim arises as a condition precedent to the commencement of a tort action. The plaintiff served no notice of claim until June 2021 and commenced an action in January 2022, alleging violations of N.Y. Labor Law §§ 240(1), 241(6), and 200. Given the plaintiff’s failure to comply with GML § 50-e(1)(a), Meghan and her team rejected the notices of claim as untimely. The plaintiff then moved for leave to deem the notices of claim timely served nunc pro tunc. In response, Meghan and her team opposed the motion and cross-moved to dismiss the action. Read the full story...
Reprinted courtesy of Lewis Brisbois

Second Circuit Affirms Win for General Contractor on No Damages for Delay Provision

September 02, 2024 — Bill Wilson - Construction Law Zone
In NASDI, LLC v. Skanska Koch Inc. Kiewit Infrastructure Co. (JV), 2024 WL 1270188 (2d Cir. Mar. 26, 2024), the U.S. Court of Appeals for the Second Circuit affirmed the District Court’s grant of summary judgment dismissing a subcontractor’s delay claim against a general contractor on a public project in New York state. The Court enforced a typical no-damages-for-delay provision to bar the subcontractor’s breach of contract claim. The no-damages-for-delay provision in the subcontract at issue provided:

NO DAMAGE FOR DELAY. Except as otherwise provided …, Subcontractor agrees that it shall have no Claim against Contractor for any loss or damage it may sustain through delay, disruption, suspension, stoppage, interference, interruption, compression, or acceleration of Subcontractor’s Work (‘Delay Damages’) caused or directed by Contractor for any reason, and that all such Claims shall be fully compensated for by Contractor’s granting Subcontractor such time extensions as it is entitled to as a result of any of the foregoing.

Read the full story...
Reprinted courtesy of Bill Wilson, Robinson & Cole LLP
Mr. Wilson may be contacted at wwilson@rc.com

Climate Disasters Are an Affordable Housing Problem

October 01, 2024 — Juan Pablo Garnham & Arjuna Heim - Bloomberg
When Maui was devastated by wildfires in August 2023, some residents were initially fortunate. The neighborhood of Makawao, for example, was spared the worst effects of the fire that engulfed Lahaina, 35 miles to the west. Recently, though, we met a woman in that neighborhood who faces a different kind of threat: Her landlord has now demanded that she pay double her rent or face eviction. As housing advocates in the region, we’ve heard stories like this repeatedly, as residents report an acute fear of displacement and homelessness. A year after the fires killed more than 100 people, displaced 12,000 and disrupted the economy of the island, the disaster lingers for many in Maui and Hawai'i. Rents across the island have increased sharply, offering a cautionary tale for the rest of the US about how climate change, a housing crisis and the lack of adequate public policies can multiply the suffering of a community already in pain. Read the full story...
Reprinted courtesy of Bloomberg

First Circuit Finds No Coverage For Subcontracted Faulty Work

December 17, 2024 — Eric Hermanson & Austin Moody - White and Williams LLP
After almost two years' deliberation, the First Circuit last week issued its long-awaited decision in Admiral Ins. Co. v. Tocci Bldg. Corp.[1]: affirming on other grounds, and leaving in place a district court decision that found subcontracted faulty work was not an "occurrence" and did not lead to covered “property damage” under Massachusetts law. The decision leaves Massachusetts among a number of states where general contractors should not expect coverage from their commercial general liability (CGL) insurers for damage falling within the contractor’s scope of work. Since the "scope of work" – where general contractors are involved – often encompasses an entire project, contractors who want coverage in Massachusetts should take care to make alternative arrangements: transferring risk to subcontractors through indemnity provisions and additional-insured endorsements, or relying on other policy forms where available. Reprinted courtesy of Eric Hermanson, White and Williams LLP and Austin Moody, White and Williams LLP Mr. Hermanson may be contacted at hermansone@whiteandwilliams.com Mr. Moody may be contacted at moodya@whiteandwilliams.com Read the full story...

Congratulations to Partner Nicole Whyte on Receiving the Marcus M. Kaufman Jurisprudence Award

September 30, 2024 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
On Thursday, September 19th, BWB&O Partner Nicole Whyte and her fellow recipients Michael Ermer and Hon. Kirk Nakamura (Ret.) were honored at this year’s Jurisprudence Awards Dinner, a fundraiser benefitting the Anti-Defamation League! Thank you to BWB&O Co-Founder and Nicole’s longtime business partner and friend Keith Bremer for his thoughtful introduction and for presenting her with the award, and to BWB&O’s team who joined the event to support Nicole Whyte. Since 1993, the Anti-Defamation League has presented the Marcus M. Kaufman Jurisprudence Award to attorneys who make exceptional contributions to the legal profession and community. ADL’s mission is to stop defamation and secure justice and fair treatment for all people. To learn more about ADL, please visit adl.org Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

Real Estate & Construction News Roundup (8/6/24) – Construction Tech Deals Surge, Senators Reintroduce Housing Bill, and Nonresidential Spending Drops

September 16, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, cybersecurity attacks target contractors, U.S. banks report weaker profits, additional commercial real estate is distressed, and more!

Spending dropped in almost half of nonresidential subcategories in June, with the decrease stemming from higher interest rates, tighter credit conditions and a softening economy. (Sebastian Obando, Construction Dive)
Despite the decline in investment dollars for construction technology, the number of deals surged by 18% year-over-year, indicating sustained interest and activity in the sector. (Sebastian Obando, Construction Dive)
As cybersecurity attacks on U.S.-based businesses ramp up, general contractors are not immune. (Jen A. Miller, Construction Dive)

Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

COLUMBUS OHIO CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES