Washington Court Denies Subcontractor’s Claim Based on Contractual Change and Notice Provisions
January 29, 2024 —
Wendy Rosenstein - Ahlers Cressman & Sleight PLLCThe recent unpublished case, Cascade Civil Construction, LLC v. Jackson Dean Construction, Inc., et al.,[1] provides a legal justification for contractors to require a directive or change order in advance of performing changed work—thereby preventing the party who requested the changed work from later arguing that notice provisions were not complied with.
In the case, Jackson Dean, the prime contractor, hired Cascade to perform excavation work on a project to build a new Costco Corporate headquarters. Due to the Covid-19 pandemic and other issues, Jackson Dean directed resequencing, which required Cascade to perform excavation concurrent to dewatering. Jackson Dean also required deeper-than-planned excavation under one of the buildings.
Read the full story...Reprinted courtesy of
Wendy Rosenstein, Ahlers Cressman & Sleight PLLCMs. Rosenstein may be contacted at
wendy.rosenstein@acslawyers.com
Surplus Lines Carrier Can Force Arbitration in Louisiana Despite Statute Limiting Arbitration
February 12, 2024 —
Tred R. Eyerly - Insurance Law HawaiiThe federal district court granted the surplus lines insurer's motion to compel arbitration despite a Louisiana statute barring policies from depriving courts of jurisdiction in cases against insurers. Queens Beauty Supply, LLC v. Indep.Specialty Ins. Co., 2023 U.S. Dist. LEXIS 195372 (E.D. La. Oct. 31, 2023).
Hurricane Ida damaged property leased by Queens. Queens filed suit against its insurer, Independent Specialty Insurance Company (ISIC) for breath of contract and bad faith for failing to pay the full amount Queens contends it was owed for the damage. ISIC moved to compel arbitration.
Queens argued that ISIC waived its right to enforce the policy's arbitration clause by its actions before the court, including failing to opt-out of the settlement program adopted for Hurricane Ida cases. The court disagreed, ISIC had taken no overt act that evidenced a desire to resolve the instant dispute through litigation rather than arbitration. ISIC asserted as an affirmative defense that Queens's claims were barred by the arbitration clause in the policy. ISIC then participated in the settlement program for Hurricane Ida cases, which evidences a desire to settle the dispute, not to resolve it by litigation. Therefore, ISIC had not waived its right to arbitrate.
Read the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Hirer Not Liable Under Privette Doctrine Where Hirer Had Knowledge of Condition, but not that Condition Posed a Concealed Hazard
December 11, 2023 —
Garret Murai - California Construction Law BlogThe Privette doctrine, so-called because of a case of the same name,
Privette v. Superior Court, 5 Cal.4th 698 (1993), provides a rebuttable presumption that a hirer is not liable for workplace injuries sustained by employees of hired parties. In other words, if a property owner hires a contractor, and one of the contractor’s employees gets injured while working on the property, there is a rebuttable presumption that the property owner is not liable for the employee’s injuries, the rationale being that because the contractor is required to carry workers’ compensation insurance the contractor is in the better position to absorb losses incurred a workplace injury.
There are, however, two widely recognized exceptions to the Privette doctrine. The first, is the Hooker exception, again named after a case of the same name,
Hooker v. Department of Transportation, 27 Cal.th 198 (2002), which provides that a hirer is liable for injuries to a hired parties’ employees, if the hirer retained control over the work being performed, negligently exercised that control, and the negative exercise of that control contributed to the employee’s injury.
Read the full story...Reprinted courtesy of
Garret Murai, Nomos LLPMr. Murai may be contacted at
gmurai@nomosllp.com
Federal Regulatory Recap: A Summary of Recent Rulemaking Actions Taken or Proposed Affecting the Energy Industry
December 16, 2023 —
Anthony B. Cavender - Gravel2Gavel Construction & Real Estate Law BlogIt is clear that these have been busy months for federal environmental regulators, especially those working at EPA, the federal departments and the Council on Environmental Quality. Even the Department of Agriculture has found itself coping with greenhouse gases (GHG) issues in its administration of the laws applicable to agriculture and the national forests. The ambitious scope of the current “all of government” approach may be discerned after learning how many disparate federal agencies are employed in implementing this policy. So many actions have been proposed or completed that some state officials are experiencing “comment fatigue” because they are being overwhelmed by the scope, size, and complexity of these federal initiatives. The Environmental Protection Agency is, of course, at the forefront of these actions and activities, as described below.
Read the full story...Reprinted courtesy of
Anthony B. Cavender, PillsburyMr. Cavender may be contacted at
anthony.cavender@pillsburylaw.com
Construction Litigation Roundup: “This Is Sufficient for Your Purposes …”
April 08, 2024 —
Daniel Lund III - Lexology… but just barely.
Federal courts are “notice” pleading courts. One source writes: “Notice pleading refers to pleading standards that merely notify the opposing party and court of the general issues in the case. In contrast to fact pleading standards, notice pleading standards do not require pleadings to include hyper-detailed facts in support of each claim.”
Some state courts – including Louisiana – are fact pleading courts. Ordinarily, no one practicing in Louisiana state courts would describe the fact pleading requirements for initiating a lawsuit as mandating “hyper-detailing” of the facts, but … why risk it?
In a construction mechanics lien case – the jurisprudence for which requires that courts strictly construe the related law because liens empower lien holders with rights which are “in derogation” of common property ownership rights – the defendant was successful in having the trial court dismiss a lien suit for failing to affirmatively set forth in the complaint (a “petition” in Louisiana) the date of substantial completion. The lien claimant appealed.
Read the full story...Reprinted courtesy of
Daniel Lund III, PhelpsMr. Lund may be contacted at
daniel.lund@phelps.com
Compliance with Contractual and Jurisdictional Pre-Suit Requirements is Essential to Maximizing Recovery
November 27, 2023 —
Michael S. Levine, Geoffrey B. Fehling & Charlotte Leszinske - Hunton Insurance Recovery BlogTimely notice is an important first step in a successful insurance recovery. But insurance policies are not always straightforward in identifying how, when, and to whom notice must be provided. Some states may also impose additional procedural hurdles, including requiring policyholders to contact their insurers before filing suit (the idea behind this requirement is that it may avoid litigation). Failing to comply with pre-suit requirements can hurt the policyholder’s recovery, as illustrated in a recent decision from the Northern District of Texas.
In NewcrestImage Holdings, LLC v. The Travelers Lloyds Insurance Company, No. 2:23-cv-039-BR (N.D. Tex. Oct. 17, 2023), the court considered whether NewcrestImage had forfeited its right to recover attorneys’ fees by failing to give Travelers pre-suit notice. NewcrestImage had filed suit against Travelers to obtain coverage for damage to its hotel property arising out of Winter Storm Uri. In its answer, Travelers asserted that NewcrestImage failed to provide the insurer with pre-suit notice as required under the Texas Insurance Code, and that if NewcrestImage successfully proved it was entitled to coverage, NewcrestImage’s failure to provide pre-suit notice precluded it from recovering attorneys’ fees. Travelers later moved to strike the claim for attorneys’ fees on that basis.
Reprinted courtesy of
Michael S. Levine, Hunton Andrews Kurth,
Geoffrey B. Fehling, Hunton Andrews Kurth and
Charlotte Leszinske, Hunton Andrews Kurth
Mr. Levine may be contacted at mlevine@HuntonAK.com
Mr. Fehling may be contacted at gfehling@HuntonAK.com
Ms. Leszinske may be contacted at cleszinske@HuntonAK.com
Read the full story...
Appraisal Panel Can Determine Causation of Loss under Ohio Law
February 19, 2024 —
Tred R. Eyerly - Insurance Law HawaiiThe federal district court granted the insured's motion to compel an appraisal that would include a determination of causation of the loss. Eagle Highland Owners Association v. State Farm Fire and Casualty Co., 2023 U.S. Dist. LEXIS 220937 (S.D. Ohio Dec. 12, 2023).
Plaintiff argued its property suffered wind and hail damage from a storm on June 18, 2021. A claim was submitted to State Farm. State Farm's investigation determined the loss to be $0.00. Plaintiff's investigator determined the loss to be $586,647.08 in repair costs.
State Farm opposed appraisal because, in its view, the damage arose from a loss in 2019, not from the June 18, 2021 storm. Plaintiff submitted a loss claim in 2019 for damage that State Farm alleged was exactly the same as the damage alleged in the loss claim for the June 18, 2021 storm. Therefore, State Farm did not view the matter as a dispute over an amount of loss, but rather over whether a loss even occurred on June 18, 2021.
Read the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Mechanic’s Liens- Big Exception
January 22, 2024 —
Christopher G. Hill - Construction Law MusingsMusings has discussed mechanic’s liens on
numerous occasions.
As we discussed in earlier posts, the general rule is that a
mechanic’s lien jumps to the head of the line of liens when filed. This is true in most instances. In the typical case, a contractor puts up a building and, when the owner refuses payment, it files a mechanic’s lien that takes priority over all other liens on that property, including the construction loan
deed of trust (or
mortgage, depending on your state’s property laws).
Read the full story...Reprinted courtesy of
The Law Office of Christopher G. HillMr. Hill may be contacted at
chrisghill@constructionlawva.com