Enforceability of Contract Provisions Extending Liquidated Damages Beyond Substantial Completion
April 15, 2024 —
Stu Richeson - The Dispute ResolverThis post takes a look at the enforceability of contract provisions providing for liquidated delay damages after substantial completion. Typically, the assessment of liquidated delay damages ends at substantial completion of a project. However, various standard form contracts, including some of the ConsensusDocs and EJCDC contracts, contain elections allowing for the parties to agree on the use of liquidated damages for failing to achieve substantial completion, final completion, or project milestones. The standard language in the AIA A201 leaves it up to the parties to define the circumstances under which liquidated damages will be awarded.
Courts are split on the enforceability of provisions that seek to assess liquidated damages beyond substantial completions. Courts in some jurisdictions will not impose liquidated damages after the date of substantial completion on the ground that liquidated damages would otherwise become a penalty if assessed after the owner has put the project to its intended use. Perini Corp. v. Greate Bay Hotel & Casino, Inc., 129 N.J. 479, 610 A.2d 364 (1992). When the terms are clear, other jurisdictions will enforce contract terms providing for liquidated damages until final completion, even if the owner has taken beneficial use of the facility. Carrothers Const. Co. v. City of S. Hutchinson, 288 Kan. 743, 207 P.3d 231 (2009).
Read the full story...Reprinted courtesy of
Stu Richeson, PhelpsMr. Richeson may be contacted at
stuart.richeson@phelps.com
Illinois Supreme Court Finds Construction Defect Claim Triggers Initial Grant of Coverage
February 26, 2024 —
Tred R. Eyerly - Insurance Law HawaiiThe Illinois Supreme Court found that the underlying allegations addressing construction defects were sufficient to establish "property damage" caused by an "occurrence."Acuity v. M/I Homes of Chicago, LLC, 2023 Ill. LEXIS 1019 (Ill. Nov. 30, 2023).
M/I Homes was the general contractor for a residential townhome development. The Owners' Association sued for breach of conract and breach of the implied warranty of habitability against M/I Homes. The complaint alleged that M/I Homes' subcontractors caused construction defects by using defective materials, conducting faulty workmanship and failing to comply with applicable building codes. The defects included leakage and uncontrolled water with moisture in locations in the buildings where it was not intended or expected. The Association further alleged that M/I Homes did not intend to cause the construction defects nor did it expect or intend the resulting property damage, such as damage to other building materials. The complaint further alleged that M/I Homes did not perform any of the construction work and that the subconractors performed all the work on its behalf.
Read the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Don’t Ignore a Notice of Contest of Lien
April 29, 2024 —
David Adelstein - Florida Construction Legal UpdatesA recent case, Jon M. Hall Company, LLC v. Canoe Creek Investments, LLC, 49 Fla.L.Weekly D812a (Fla. 2d DCA 2024), demonstrates four important things when it comes to liens:
- An owner can shorten the time period to foreclose on the lien, whether against the real property or a lien transfer bond, to 60 days by recording a notice of contest of lien;
- An owner can transfer a lien to a lien transfer bond during litigation;
- An owner can record a notice of contest of lien to force the lienor to amend its lawsuit to sue the lien transfer bond surety within 60 days; and
- A contractors’ failure to amend its lawsuit to sue the lien transfer bond within 60 days will extinguish its rights to pursue a claim against the lien transfer bond, and will otherwise extinguish the lien, fairly or unfairly.
Read the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Best Practices: Commercial Lockouts in Arizona
April 15, 2024 —
Patrick Tighe - Snell & Wilmer Real Estate Litigation BlogIf a tenant defaults under a commercial lease, Arizona law permits the landlord to re-take possession of the premises by locking out the defaulting tenant. However, if the landlord’s lockout is wrongful, the landlord may be liable for the damages the tenant sustains because of the wrongful lockout. To minimize such liability, here are some general best practices to follow when locking out a defaulting tenant:
- Do Not Breach the Peace. It is vital when performing a lockout to not breach the peace. What constitutes a “breach of the peace” depends on the particular circumstances at hand. For example, if a tenant arrives during the lockout and becomes angry or threatens violence, the landlord should stop performing the lockout and return at a later time. As a general rule of thumb, it is best to perform lockouts in the early morning hours or in the late evening hours when the landlord is less likely to encounter the tenant.
- Provide A Notice of Default. Many commercial leases require the landlord to provide a notice of default before the landlord can lock out a defaulting tenant. Check, double check, and triple check that the landlord followed the lease’s notice of default provisions correctly, including that the landlord sent the notices to all required parties in accordance with the time requirements set forth in the lease.
Read the full story...Reprinted courtesy of
Patrick Tighe, Snell & WilmerMr. Tighe may be contacted at
ptighe@swlaw.com
Congratulations to BWB&O’s Newport Beach Team on Obtaining a Defense Verdict in Favor of their Subcontractor Client!
April 02, 2024 —
Dolores Montoya - Bremer Whyte Brown & O'Meara LLPBremer Whyte Brown & O’Meara’s Newport Beach Partner Morgan Stiefel and Associate Brandon Cook obtained a defense verdict after years-long litigation in favor of their subcontractor client.
This lawsuit stemmed from a claim made by Plaintiff for eye injuries arising out of claimed negligence and strict liability associated with our client’s performance of a sandblasting job at a construction site adjacent to Plaintiff’s home. Plaintiff alleges that while she was in her backyard, sand hit her in the eyes at a high velocity speed, resulting in permanent damage to her eyes.
We argued our clients took all necessary safety precautions in the performance of this job, and Plaintiff’s eye irritation symptoms could not have been caused by our client. All of her alleged injuries were either pre-existing or could be explained by circumstances other than our client’s actions. Through expert testimony and our arguments, we were able to show the jury that Plaintiff lied about the sand entering her eyes at a high velocity and her symptoms being caused by our clients’ performance of the sandblasting job.
Read the full story...Reprinted courtesy of
Dolores Montoya, Bremer Whyte Brown & O'Meara LLP
Cooperating With Your Insurance Carrier: Is It a Must?
January 02, 2024 —
Susana Arce - Saxe Doernberger & Vita, P.C.A majority of insurance policies require the insured to cooperate with the insurer. The cooperation clause generally states, “the insured agrees to Cooperate with us in the investigation, settlement or defense of the suit.”
The “cooperation clause” is often an afterthought because once litigation has ensued an insured is focused on other important considerations. However, insureds should not forget that complying with the cooperation clause can make the difference between the insurer covering or denying a claim.
The Cooperation Clause in Action
The Court in
HDI Glob. Specialty SE v. PF Holdings, LLC,1 highlighted the importance of cooperating with an insurance carrier. In the underlying litigation, residents of an apartment complex sued four entities, all insured by the same insurance policy: two were named insureds and two were additional insureds. The primary insurer provided a defense for the named insureds.
Read the full story...Reprinted courtesy of
Susana Arce, Saxe Doernberger & Vita, P.C.Ms. Arce may be contacted at
SArce@sdvlaw.com
Fine Art Losses – “Canvas” the Subrogation Landscape
February 26, 2024 —
William L. Doerler - The Subrogation StrategistIf a fire or flood destroys a high-net-worth client’s fine art collection, an insurer who pays out a claim related to the loss has an incentive to pursue subrogation. This article explores some of the issues an insurer should “canvas” before pursuing subrogation for these types of claims.
Damage to fine art can occur in a number of ways. For instance, fine art may be damaged in a natural disaster – such as a flood or a wildfire. Artwork may also be accidentally damaged because of a transportation-related incident physically damaging the art. In addition, artwork may suffer fire or smoke damage from a fire within a building. Another possibility is that the artwork suffers damage because of renovations either to the insured’s home or a neighboring property. For example, a renovation contractor may damage artwork due to vibrations or leaking water. A construction worker, moreover, may turn with a tool in his hand, or trip and fall, damaging the artwork.
Read the full story...Reprinted courtesy of
William L. Doerler, White and Williams LLPMr. Doerler may be contacted at
doerlerw@whiteandwilliams.com
Largest Dam Removal Program in US History Reaches Milestone
December 11, 2023 —
Mary K. Miller - Engineering News-RecordAll work associated with removal of the first of four hydroelectric dams slated for demolition on the Klamath River completed in early November, according to the dam owner, Klamath River Renewal Corp. Demolition of the four dams on the Klamath River that flows through parts of Oregon and California is the largest dam removal project in U.S. history.
Reprinted courtesy of
Mary K. Miller, Engineering News-Record
ENR may be contacted at enr@enr.com
Read the full story...